How to write my General Project Work Order (With Deposit) document

WORK ORDER company name address address city state or province zip or postal code Phone phone number DATE. current date Order WorkOrder Bill To. company name city state or province zip or postal code

Phone phone number For. Insert what you are doing for the customer here DESCRIPTION* HOURS RATE AMOUNT TOTAL DEPOSIT REQUIRED Agreements In consideration of the mutual covenants set forth in this Agreement Customer and Company hereby agree as follows. 1. Development of Project or Services. Customer agrees to engage Company to develop the Project as described above*. 2. Delivery of Project or Services. Company will use reasonable diligence in the development of the project and endeavor to deliver to Customer an operational project no later than delivery date. Customer acknowledges however that this delivery deadline is an estimate and not required delivery date. 3. Ownership Rights. Company shall hold all right title and interest in and to all copyrights patents trade secrets and other intellectual or industrial property rights in the project or any component or characteristic thereof which are proprietary to the Company. Customer shall not do anything that may infringe upon or in any way undermine Companys right title and interest in the project as described in this paragraph 3. Notwithstanding the above Customer shall retain all of its intellectual property rights in any components it owns and transmits to Company for use in the project. 4. Compensation. For all of Companys services under this Agreement Customer shall compensate the Company in cash the amount specified in the total above. In the event Customer fails to make any of the payments referenced by the deadline set forth as invoiced Company has the right but is not obligated to pursue any or all of the following remedies. terminate the Agreement remove the project from public access bring legal action. 5. Limited Warranty and Limitation on Damages. Developers warrant the project will conform to the Specifications. If the project does not conform to the Specifications the Company shall be responsible to correct the project without unreasonable delay at the Companys sole expense and without charge to Customer to bring the project into conformance with the Specifications. This warranty shall be the exclusive warranty available to the Customer. Customer waives any other warranty express or implied. Customer acknowledges that the Company does not warrant that the project will work on all platforms. Customer acknowledges that the Company is not responsible for the results obtained by the Customer. Should the Customer cancel quit or otherwise terminate the project for any reason Company reserves the full and exclusive right to apply any monies received from the Customer against the Customers outstanding invoice or bill. Customer waives any claim for damages direct or indirect and agrees that its sole and exclusive remedy for damages either in contract or tort is the return of the consideration paid to the Company. 6. Binding Effect. This Agreement shall be binding upon and inure to the benefit of Customer and the Company and their respective successors and assigns provided that the Company may not assign any of its obligations under this Agreement without prior written consent of Customer. ACCEPTANCE OF AGREEMENT. The above prices specifications and conditions are hereby accepted. The Company is authorized to execute the project as outlined in this Agreement. Payment will be made as proposed above. company name

By signator authorized signature or signer. Job title of signator authorized signature or signer. Date when the contact was signed company name By signator authorized signature or signer.

and so on...

A Document from Contract Pack

The editable General Project Work Order (With Deposit) template - complete with the actual formatting and layout is available in the retail Contract Packs.

New 2014 Editions
Proposal Software Help

Pin this General Project Work Order (With Deposit)General Project Work Order (With Deposit) : View General Project Work Order (With Deposit)

Proposal Kit Professional
Proposal Kit TestimonialTime and time

again the most minor of normally overlooked clauses have saved our collectives asses when things turn rough with a particular client. Proposal Kit IS the reason we are still in business; a PROFITABLE BUSINESS after all these years."

Proposal Kit TestimonialsOver 500 Proposal Kit testimonials!
Contract Packs with the General Project Work Order (With Deposit) document

Document Length: 2 Pages

Usage: For small, low risk jobs

Use the General Project Work Order for low cost, low risk work. For use with small projects, the short form agreement consolidates everything down to two pages with both an agreement and payment terms. Use this version for small, lower cost and lower risk jobs that do not need a lot of specialty protections of a larger contract. This variation is the same as General Project Work Order (No Deposit) and adds a line for a required deposit to start work. Typically used for low risk work in the hundreds of dollars range or less. Good for writing quick quotes.

 

Product name: Proposal Kit Professional

Produced by: Proposal Kit

Category: Software > Computer Software > Business & Productivity Software

Price: $197


Proposal Kit reviews4.9 stars, based on 587 reviews
Legal Contract Templates

Alternate documents are those which may be used instead of this document depending on your situation. Alternate documents may be better suited for different size projects, more specialized projects, variations on rights, etc.

Alternate Documents:

Related documents may be used in conjunction with this document depending on your situation. Many related documents are intended for use as part of a contract management system.

Related Documents:
General Project Work Order (With Deposit)
Disclaimers:

Cyber Sea, Inc. makes no warranty and accepts no responsibility for suitability of any materials to licensees business. Cyber Sea, Inc. assumes no responsibility or liability for errors or inaccuracies. Licensee accepts all responsibility for results obtained. Information included is not legal advice. Use of any supplied materials constitutes acceptance and understanding of these disclaimers.

Ian Lauder has been helping businesses write their proposals and contracts for over a decade. Ian is the Owner and Founder of Proposal Kit, one of the original sources of business proposal and contract software products started in 1997.

Proposal Kit Produced
By Ian Lauder

How to write my General Project Work Order (With Deposit) document

WORK ORDER company name address address city state or province zip or postal code Phone phone number DATE. current date Order WorkOrder Bill To. company name city state or province zip or postal code

Phone phone number For. Insert what you are doing for the customer here DESCRIPTION* HOURS RATE AMOUNT TOTAL DEPOSIT REQUIRED Agreements In consideration of the mutual covenants set forth in this Agreement Customer and Company hereby agree as follows. 1. Development of Project or Services. Customer agrees to engage Company to develop the Project as described above*. 2. Delivery of Project or Services. Company will use reasonable diligence in the development of the project and endeavor to deliver to Customer an operational project no later than delivery date. Customer acknowledges however that this delivery deadline is an estimate and not required delivery date. 3. Ownership Rights. Company shall hold all right title and interest in and to all copyrights patents trade secrets and other intellectual or industrial property rights in the project or any component or characteristic thereof which are proprietary to the Company. Customer shall not do anything that may infringe upon or in any way undermine Companys right title and interest in the project as described in this paragraph 3. Notwithstanding the above Customer shall retain all of its intellectual property rights in any components it owns and transmits to Company for use in the project. 4. Compensation. For all of Companys services under this Agreement Customer shall compensate the Company in cash the amount specified in the total above. In the event Customer fails to make any of the payments referenced by the deadline set forth as invoiced Company has the right but is not obligated to pursue any or all of the following remedies. terminate the Agreement remove the project from public access bring legal action. 5. Limited Warranty and Limitation on Damages. Developers warrant the project will conform to the Specifications. If the project does not conform to the Specifications the Company shall be responsible to correct the project without unreasonable delay at the Companys sole expense and without charge to Customer to bring the project into conformance with the Specifications. This warranty shall be the exclusive warranty available to the Customer. Customer waives any other warranty express or implied. Customer acknowledges that the Company does not warrant that the project will work on all platforms. Customer acknowledges that the Company is not responsible for the results obtained by the Customer. Should the Customer cancel quit or otherwise terminate the project for any reason Company reserves the full and exclusive right to apply any monies received from the Customer against the Customers outstanding invoice or bill. Customer waives any claim for damages direct or indirect and agrees that its sole and exclusive remedy for damages either in contract or tort is the return of the consideration paid to the Company. 6. Binding Effect. This Agreement shall be binding upon and inure to the benefit of Customer and the Company and their respective successors and assigns provided that the Company may not assign any of its obligations under this Agreement without prior written consent of Customer. ACCEPTANCE OF AGREEMENT. The above prices specifications and conditions are hereby accepted. The Company is authorized to execute the project as outlined in this Agreement. Payment will be made as proposed above. company name

By signator authorized signature or signer. Job title of signator authorized signature or signer. Date when the contact was signed company name By signator authorized signature or signer.

Job title of signator authorized signature or signer. Date when the contact was signed Customer Initials Company Initials

How do you write a General Services Agreement document? (alternate or related contract document)

SERVICES AGREEMENT THIS AGREEMENT is made this current day day of current month current year by and between company name Company and company name Customer Recitals A. Company has experience and expertise in Insert description of the type of services you have experience in providing B. Customer desires to have Company provide services for them. C. Company desires to provide services to Customer on the terms and conditions set forth herein the Services Agreements

In consideration of the mutual covenants set forth in this Agreement Customer and Company hereby agree as follows. 1. Services Rendered. Company agrees to render and be compensated for the Services according to the terms listed on Exhibit attached hereto. 2. Scope of Work. Company agrees to provide Services pursuant to the Scope of Work set forth in Exhibit attached hereto the Scope of Work

3. Delivery of Services. Company will use reasonable diligence in the rendering of the Services. Customer acknowledges however that any stated delivery deadline and the other payment milestones listed in Exhibit are estimates and are not required delivery dates. 4. Ownership Rights. Customer shall retain all of its intellectual property rights in any text images or other components it owns and transmits to Company for use in the Services. Customer shall hold the copyright for the agreed upon version of the Services as delivered and Customers copyright notice may be displayed in the final version. Company retains exclusive rights to pre existing material it uses in Customers project s. Customer does not have right to reuse resell or otherwise transfer material owned by Company or third parties. Companys materials shall be defined as set forth in Exhibit attached. 5. Compensation. For all of Companys services under this Agreement Customer shall compensate Company in cash pursuant to the terms of Exhibit attached hereto. In the event Customer fails to make any of the payments referenced in Exhibit by the deadline set forth in Exhibit Company have the right but is not obligated to pursue any or all of the following remedies. terminate the Agreement remove or withhold services or deliverables or bring legal action. 6. Confidentiality. Customer and Company acknowledge and agree that the Scope of Work and all other documents and information related to the development of the Services the Confidential Information will constitute valuable trade secrets of Company. Customer shall keep the Confidential Information in confidence and shall not at any time during or after the term of this Agreement without Companys prior written consent disclose or otherwise make available to anyone either directly or indirectly all or any part of the Confidential Information. Excluded from the Confidential Information definition is anything that can be seen by the public.

7. Limited Warranty and Limitation on Damages. Company warrants the Services will conform to the Scope of Work. If the Services or Deliverables do not conform to the Scope of Work Company shall be responsible to correct the Services or Deliverables without unreasonable delay at Companys sole expense and without charge to Customer to bring the Services or Deliverables into conformance with the Scope of Work. This warranty shall be the exclusive warranty available to Customer. Customer waives any other warranty express or implied. Customer acknowledges that Company is not responsible for the results obtained by Customer on the Services. Customer waives any claim for damages direct or indirect and agrees that its sole and exclusive remedy for damages either in contract or tort is the return of the consideration paid to Company as set forth in Exhibit attached hereto. 8. Independent Contractor. Company shall be retained as an independent contractor. Company will be fully responsible for payment of its own income taxes on all compensation earned under this Agreement. Customer will not withhold or pay any income tax social security tax or any other payroll taxes on Companys behalf. Company understands that it will not be entitled to any fringe benefits that Customer provides for its employees generally or to any statutory employment benefits including without limitation workers compensation or unemployment insurance. 9. Equipment. Customer agrees to make available to Company for Companys use in performing the services required by this Agreement such items of hardware and software as Customer and Company may agree are reasonably necessary for such purpose. 10. General Provisions. 10 Entire Agreement.

This Agreement contains the entire agreement between the parties relating to the subject matter hereof and supersedes any and all prior agreements or understandings written or oral between the parties related to the subject matter hereof. No modification of this Agreement shall be valid unless made in writing and signed by both of the parties hereto. 10 Governing Law. This Agreement shall be governed by and construed in accordance with the laws of the State of state or province. Exclusive jurisdiction and venue shall be in the county County state or province Superior Court. 10 Binding Effect. This Agreement shall be binding upon and inure to the benefit of Customer and Company and their respective successors and assigns provided that Company may not assign any of its obligations under this Agreement without Customers prior written consent. 10 Waiver. The waiver by either party of any breach or failure to enforce any of the terms and conditions of this Agreement at any time shall not in any way affect limit or waive such partys right thereafter to enforce and compel strict compliance with every term and condition of this Agreement. 10 Good Faith.

Each party represents and warrants to the other that such party has acted in good faith and agrees to continue to so act in the negotiation execution delivery performance and any termination of this Agreement. 10 Right to Remove Services. In the event Customer fails to make any of the payments set forth on Exhibit within the time prescribed in Exhibit Company has the right to remove or withhold the Services or Deliverables until payment in full is made plus accrued late charges of 2% per month. 10 Indemnification. Customer warrants that everything it gives Company to use in the delivery of the Services or any deliverable is legally owned or licensed to Customer. Customer agrees to indemnify and hold Company harmless from any and all claims brought by any third party relating to any aspect of the Services including but without limitation any and all demands liabilities losses costs and claims including attorneys fees arising out of injury caused by Customers products services material supplied by Customer copyright infringement and defective products sold via the Services or Deliverables. 10 Use of Services for Promotional Purposes. Customer grants Company the right to reference the Services or Deliverables or the Customers name for promotional purposes and or to cross link it with other Services offered by Company.

10 No Responsibility for Theft. Company has no responsibility for any third party taking stealing destroying or otherwise ruining all or any part of the Services or Deliverables rendered under this Agreement. 10. 10 Attorneys Fees. In the event any party to this Agreement employs an attorney to enforce any of the terms of the Agreement the prevailing party shall be entitled to recover its actual attorneys fees and costs including expert witness fees. 10. 11 Identification of Company. Customer agrees that Companys identification may be associated with the Services or Deliverables as the creators. Customer also agrees to put Companys copyright notices on the Services or Deliverables and the relevant content therein. 10. 12 No Responsibility for Loss. Company is not responsible for any down time lost files improper links or any other loss that may occur from any service or deliverable related to Companys work or the rendering of the Services or Deliverables.

10. 13 Transfer of Rights. In the event Company is unable to continue maintenance of the Services Customer shall have non exclusive rights to use pre existing material see Exhibit owned by Company in connection with Customers Services. The parties represent and warrant that on the date first written above they are authorized to enter into this Agreement in its entirety and duly bind their respective principals by their signatures below. EXECUTED as of the date first written above. company name By signator authorized signature or signer. Job title of signator authorized signature or signer.

Date when the contact was signed company name By signator authorized signature or signer. Job title of signator authorized signature or signer. Date when the contact was signed

Customer Initials Company Initials

How to write my Project Contract Acceptance Signoff Form document (alternate or related contract document)

company name Project Acceptance Signoff address address city state or province zip or postal code Phone phone number DATE. current date Order WorkOrder Client.

company name city state or province zip or postal code Phone phone number For. General Description of Project Deliverables Please initial the following sections which detail the projects deliverables contracted between company name and company name and sign the Acceptance of Agreement at the bottom of this document. Initials Description of Completed Milestone Acceptance of Milestone #1 description here

Acceptance of Milestone #2 description here Acceptance of Milestone #3 description here Acceptance of Milestone #n description here Acceptance of Project per Contract Specifications. ACCEPTANCE OF AGREEMENT. I certify that have received the above project deliverables from company name and that the deliverables listed above have been demonstrated delivered or otherwise completed to my satisfaction. Best Practice Note. If billing by credit card the above line should include permission to charge their credit card. This helps reduce your chargeback exposure. Example. Florentine Design Group LLC may now charge the final installment of 390 to AMEX ************345 for completion of the project.

Clients signature

Writing the Project Copyright Transfer Contract document (alternate or related contract document)

TRANSFER OF COPYRIGHT AGREEMENT THIS AGREEMENT is made this current day day of current month current year by and between company name hereafter referred to as Author and company name hereafter referred to as Client PART A. The purpose of this Agreement hereafter referred to as the Agreement is to act as transfer of copyright for the attached work Exhibit hereafter referred to as the Article from company name to company name effective as of the date of this agreement. Note. If article was prepared as part of the writers duties for his her employer work for hire this agreement must be signed and authorized by the employer as the Author. If the Article was prepared by U. S. Government employee as part of his her official duties please refer to Part B.

Copyright to the above work including without limitation the right to publish the work in whole or in part in any and all forms of media now or hereafter known is hereby transferred to company name for the following publication uses. Insert details of the specified usage of the content. Copyright to the listed original and unpublished article and subsequent revisions errata or abstracts submitted by the above author the Article is hereby transferred to company name for the full term thereof throughout the world subject to the following rights that the author may freely exercise and to acceptance of the Article for publication and use in company name business. company name shall have the right to register as claimant copyright to the Article in its name whether used individually or as part of another work or medium in which the Article is part of. The author shall retain the following rights so long as the author agree that all copies of the Article made under any of these following rights shall include notice of the company name copyright. 1 All proprietary rights and patent rights other than copyright and the publication rights transferred to company name.

2 The nonexclusive right after publication by company name to give permission to third parties to republish the Article or translation thereof or excerpts therefrom without obtaining permission from company name provided the company name published version is not used for this purpose and provided the Article is not to be published in another journal or web site. If the company name version is used permission from company name must be obtained. 3 The right to post their own author versions of reprints and revisions to use all or part of the Article without revision or modification including the company name published version in personal collection or other publications of the authors own works so long as the company name copyright notice is attached. 4 The right of an employer to make copies of the Article so long as it was prepared by an employee within the scope of his or her employment and only for the employers own internal use. 5 In the case of work performed under United States Government contract Publisher grants the U. S. Government royalty free permission to reproduce all or portions of the Article and to authorize others to do so for U. S. Government purposes. In the event that the Article is not accepted and published by company name this agreement becomes null and void. By signing this Agreement the author warrants that the Article is original with the author and does not infringe any copyright or violate any other right of any third parties and that the Article has not been published elsewhere and is not being considered for publication elsewhere in any form except as provided herein. If each authors signature does not appear below the signing author represent that they sign this Agreement as authorized agents for and on behalf of all the authors and that this Agreement and authorization is made on behalf of all the authors. The signing author or in the case of work made for hire the signing employer also warrant that they have the full power to enter into this Agreement and to make the grants contained herein. If any provision of this agreement is held to be unenforceable the enforceability of the remaining provisions shall in no way be affected or impaired thereby. This agreement and any disputes arising here under shall be governed by the laws of state or province state without regard to conflicts of laws principles. failure by any party to exercise or delay in exercising right or power conferred upon it in this agreement shall not operate as waiver of any such right or power.

company name Name. Signature. Date. PART B. In the case of work that was performed under U. S. Government contract but you are not U. S. Government employee please sign the transfer form above and review Item above. The following certifies that the author of the listed Article see Exhibit are employees of the U. S. Government and the work was performed as part of their employment and that the Article is not subject to protection under U. S. Copyright. Name. Signature.

Govt. Organization. Date. Author Initials Client Initials

How to write my Project Development Short Form Contract document (alternate or related contract document)

company name Work Order address address city state or province zip or postal code Phone phone number DATE. current date

Order WorkOrder Bill To. company name city state or province zip or postal code Phone phone number For. What you are doing for the customer here

DESCRIPTION HOURS RATE AMOUNT TOTAL Agreements In consideration of the mutual covenants set forth in this Agreement Customer and Developers hereby agree as follows. 1. Development of Web Site Digital Media. Developers agree to develop the Web Site and other Digital Media according to the terms expressed by the customer and recommended by the developers. 2. Delivery of Web Site Digital Media. Developers will use reasonable diligence in the development of the Web Site and endeavor to deliver to Customer an operational Web Site no later than delivery date. Customer acknowledges however that this delivery deadline and the other payment milestones listed in Section are estimates and are not required delivery dates. 3. Ownership Rights. Developers shall hold all right title and interest in and to the Web Site Media. Specifically but without limitation Developer shall hold all right title and interest in and to all text graphics animation audio components and digital components of the Web Site the Content all interfaces navigational devices menus menu structures or arrangements icons help and other operational instructions and all other components of any source or object computer code that comprises the Web Site all literal and non literal expressions of ideas that operate cause create direct manipulate access or otherwise affect the Content and all copyrights patents trade secrets and other intellectual or industrial property rights in the Web Site or any component or characteristic thereof. Customer shall not do anything that may infringe upon or in any way undermine Developers right title and interest in the Web Site as described in this paragraph 3. Notwithstanding the above Customer shall retain all of its intellectual property rights in any text images or other components it owns and transmits to Developers for use in the Web Site. 4. Compensation. For all of Developers services under this Agreement Customer shall compensate Developers in cash the amount specified in the total above. In the event Customer fails to make any of the payments referenced by the deadline set forth in Exhibit Invoice Developers have the right but are not obligated to pursue any or all of the following remedies. terminate the Agreement remove the Web Site and or Digital Media bring legal action. 5. Limited Warranty and Limitation on Damages. Developers warrant the Web Site will conform to the Specifications. If the Web Site does not conform to the Specifications Developers shall be responsible to correct the Web Site without unreasonable delay at Developers sole expense and without charge to Customer to bring the Web Site into conformance with the Specifications. This warranty shall be the exclusive warranty available to the Customer. Customer waives any other warranty express or implied. Customer acknowledges that Developers do not warrant that the Web Site will work on all platforms. Customer acknowledges that Developers are not responsible for the results obtained by the Customer on the Web Site. Customer waives any claim for damages direct or indirect and agrees that its sole and exclusive remedy for damages either in contract or tort is the return of the consideration paid to Developers as set forth in Exhibit attached hereto. 6. Binding Effect. This Agreement shall be binding upon and inure to the benefit of Customer and Developers and their respective successors and assigns provided that Developers may not assign any of his obligations under this Agreement without Customers prior written consent. ACCEPTANCE OF AGREEMENT. The above prices specifications and conditions are hereby accepted. The designer is authorized to execute the project as outlined in this agreement. Payment will be made as proposed above. Customers signature Designers signature Date THANK YOU FOR YOUR BUSINESS.

A Document from Contract Pack

The editable General Project Work Order (With Deposit) template - complete with the actual formatting and layout is available in the retail Contract Packs.

Proposal Kit on FacebookFacebook
Proposal Kit on PinterestPinterest
Proposal Kit on Google+Google+
Proposal Kit on TwitterTwitter
Proposal Kit RSS FeedRSS
Proposal Kit NewsletterNewsletter