Writing the Data Backup and Storage Contract document

DATA BACKUP AND STORAGE AGREEMENT THIS AGREEMENT is made this current day day of current month current year by and between company name Company and company name Customer The purpose of this Agreement hereafter referred to as the Agreement is to set forth contract arrangement under which Company will provide offsite Data Backup and Storage services Data Backup and Storage Services on behalf of Customer. Agreements In consideration of the mutual covenants set forth in this Agreement Company and Customer hereby agree as follows.

1. Terms. Subject to the terms and conditions of this Agreement Company will provide Data Backup and Storage Services for Customer subject to the following terms. a Length of Service. Customer agrees to an initial six month or twelve month contractual term of service Term The length of contract required is based on the type of service desired by Customer and shall be determined solely by Company. b Service Start Date. The first payment plus setup charges if any shall be due in advance of any service provided. Service shall begin upon Company receipt of payment for such first Term of service or upon mutually agreed upon alternate date. c Renewal by Customer.

This Agreement will automatically renew for successive six or twelve month Terms unless canceled in writing by Customer at least days prior to the end of Term renewal date. Renewal prices are subject to change. Renewal of services by Customer indicates agreement to any contract revisions and price changes. Renewal fees for the following term will be automatically invoiced to Customers account. d Type of Service s. Company will provide Customer with custom offsite data backup and storage solution according to the attached Specifications Exhibit and may comprise one or more of the following types of backups or consulting. Backup and Restoration of Data Consulting. Company consultants will make recommendations to Customer on the type of backups and storage that fit the Customers goals and objectives. Consultants will take into consideration the amount of storage space as well as the speed of the restoration and retrieval of archived data. Consultants may recommend combination of different backup and incremental backup types to meet Customer goals and objectives. Standard Copy Backup. A standard copy backup that copies all selected files but will not mark each file as archived or otherwise flagged as having been backed up. Standard Daily Backup. A standard daily backup that copies all selected files that have been modified on the day that the backup is performed however the files are not marked as archived or otherwise flagged as having been backed up. Standard Incremental Backup. A standard incremental backup that copies all of the data that has been modified since the last standard incremental backup. Archival Backup. An archival backup that copies all of the data whether or not it has been modified since the last backup.

and so on...

A Document from Contract Pack

The editable Data Backup and Storage Contract template - complete with the actual formatting and layout is available in the retail Contract Packs.

New 2014 Editions
Proposal Software Help

Pin this Data Backup and Storage ContractData Backup and Storage Contract : View Data Backup and Storage Contract

Proposal Kit Professional
Proposal Kit TestimonialAfter spending

weeks looking at all the others, I found this has to be the best, for ease of use and producing professional looking documentation. I really do not know where our company would be without it."

Proposal Kit TestimonialsOver 600 Proposal Kit testimonials!
Contract Packs with the Data Backup and Storage Contract document

Document Length: 5 Pages

Usage: Computer services

The Data Backup and Storage contact is used for providing backup services to a customer. Covers issues such as you not being responsible for loss of data between backups or virus software on the customer's system or data integrity of the backups (i.e., what happens if a corrupt database is backed up), unless you are contracted to also ensure data integrity.

 

Product name: Proposal Kit Professional

Produced by: Proposal Kit

Category: Software > Computer Software > Business & Productivity Software

Price: $197


Proposal Kit reviews4.9 stars, based on 611 reviews
Legal Contract Templates

Alternate documents are those which may be used instead of this document depending on your situation. Alternate documents may be better suited for different size projects, more specialized projects, variations on rights, etc.

Alternate Documents:

Related documents may be used in conjunction with this document depending on your situation. Many related documents are intended for use as part of a contract management system.

Related Documents:
Data Backup and Storage Contract
Disclaimers:

Cyber Sea, Inc. makes no warranty and accepts no responsibility for suitability of any materials to licensees business. Cyber Sea, Inc. assumes no responsibility or liability for errors or inaccuracies. Licensee accepts all responsibility for results obtained. Information included is not legal advice. Use of any supplied materials constitutes acceptance and understanding of these disclaimers.

Ian Lauder has been helping businesses write their proposals and contracts for almost two decades. Ian is the Owner and Founder of Proposal Kit, one of the original sources of business proposal and contract software products started in 1997.

Proposal Kit Produced
By Ian Lauder

How do you write a Data Backup and Storage Contract document?

DATA BACKUP AND STORAGE AGREEMENT THIS AGREEMENT is made this current day day of current month current year by and between company name Company and company name Customer The purpose of this Agreement hereafter referred to as the Agreement is to set forth contract arrangement under which Company will provide offsite Data Backup and Storage services Data Backup and Storage Services on behalf of Customer. Agreements In consideration of the mutual covenants set forth in this Agreement Company and Customer hereby agree as follows.

1. Terms. Subject to the terms and conditions of this Agreement Company will provide Data Backup and Storage Services for Customer subject to the following terms. a Length of Service. Customer agrees to an initial six month or twelve month contractual term of service Term The length of contract required is based on the type of service desired by Customer and shall be determined solely by Company. b Service Start Date. The first payment plus setup charges if any shall be due in advance of any service provided. Service shall begin upon Company receipt of payment for such first Term of service or upon mutually agreed upon alternate date. c Renewal by Customer.

This Agreement will automatically renew for successive six or twelve month Terms unless canceled in writing by Customer at least days prior to the end of Term renewal date. Renewal prices are subject to change. Renewal of services by Customer indicates agreement to any contract revisions and price changes. Renewal fees for the following term will be automatically invoiced to Customers account. d Type of Service s. Company will provide Customer with custom offsite data backup and storage solution according to the attached Specifications Exhibit and may comprise one or more of the following types of backups or consulting. Backup and Restoration of Data Consulting. Company consultants will make recommendations to Customer on the type of backups and storage that fit the Customers goals and objectives. Consultants will take into consideration the amount of storage space as well as the speed of the restoration and retrieval of archived data. Consultants may recommend combination of different backup and incremental backup types to meet Customer goals and objectives. Standard Copy Backup. A standard copy backup that copies all selected files but will not mark each file as archived or otherwise flagged as having been backed up. Standard Daily Backup. A standard daily backup that copies all selected files that have been modified on the day that the backup is performed however the files are not marked as archived or otherwise flagged as having been backed up. Standard Incremental Backup. A standard incremental backup that copies all of the data that has been modified since the last standard incremental backup. Archival Backup. An archival backup that copies all of the data whether or not it has been modified since the last backup.

Physical Storage of Backup Media. A physical location that serves as storage for Customers data data backups and related storage media. Transportation of Backup Media. Services involved in the transporting of backup media between Customer and Companys facilities or location s. e Limitations of Service. The nature of Customer data and backups is that they are stored on impermanent physical media which are subject to degradation and technological change. Company will make every effort to continually transfer or upgrade storage devices and media in order to fulfill its obligations under this agreement. Company reserves the right to transfer and upgrade all media and backups as it sees fit unless otherwise agreed upon in the Specifications. f Limitations Due to Time.

All data backup and storage is performed on pre determined schedules i. e. hourly daily weekly determined by the level of service desired and set forth in the Specifications. Company is not responsible for loss of data or absence of backup between the time backup starts and the next scheduled backup. The type of backup performed will also dictate the availability of restorable media; restore points snapshots or any other data backup or storage requirement that may be needed by the Customer at any given time. 2. End User Pricing and Compensation. End user pricing and compensation is outlined on Exhibit attached and is subject to change at the sole discretion of Company. 2 Excessive Use of Services. Company may impose an additional charge or restriction of services at any time that Customers use of the services imposes considerable effect on Company resources or system performance. Company shall have sole discretion as to what constitutes excessive use and what activity is considered violation of either the Company Acceptable Use Policy or level of service that the Customer is currently using. Company is responsible for monitoring such excessive use for the account as whole and has no responsibility to identify Customers individual end user employee or other agent who may or may not be responsible for the excessive use of services. 3. Terms of Payment.

Terms of payment are C. O. D. unless credit approval has been granted by Company. If credit approval has been granted credit terms are net days upon receipt of invoice. We reserve the right to revoke any credit extended if payment is in arrears for more than days. 4. Proprietary Information. Proprietary information exchanged here under shall be treated as such by Customer. This information shall include but not be limited to the provisions of this Agreement product and services information and pricing. Customer further agrees to not decompose disassemble decode or reverse engineer any Company program code or technology delivered to Customer or any portion thereof. 5. Censorship. Company will exercise no control whatsoever over the content of the information passing through the network email or web site. 6. Warranties. Company makes no warranties or representations of any kind whether expressed or implied for the service it is providing. Company also disclaims any warranty of merchantability or fitness for any particular purpose and will not be responsible for any damages that may be suffered by Customer including loss of data resulting from delays non deliveries or service interruptions by any cause or errors or omissions of Customer. Use of any information obtained by way of Company is at Customers own risk and Company specifically denies any responsibility for the accuracy or quality of information obtained through its services. Connection speed represents the speed of an end to end connection. Company does not represent guarantees of speed or availability of end to end connections. Company expressly limits its damages to Customer for any non accessibility time or other down time to the pro rata monthly charge during the system unavailability. Company specifically denies any responsibilities for any damages arising as consequence of such unavailability. 6 Antivirus Trojan and Malicious Code Disclaimer.

Company storage devices make use of enterprise class antivirus software in order to protect the server and detect viruses and other malicious code. Infected files will be handled per Company policy and preferences and Company will notify Customer that an infection has been detected in the data being backed up and stored by Company. Company will not under any circumstance attempt to delete repair or otherwise remove the infection in any file. Customer assumes all responsibility for data backed up on Company storage devices and media that contain virus or malicious code. Customer is responsible for implementing Customers own internal policies and procedures for opening potentially dangerous attachments and is encouraged to install antivirus software on all access points or computers using Company Data Backup and Storage Services. 6 Warranties on Restoration of Files and Data. Customer assumes all responsibility for the integrity and the suitability of the data that is to be restored. Specific requirements for testing the suitability of any data that is to be restored schedules for such testing and scenarios under which the retrieval and restoration of data and backup files will occur shall be outlined in the Specifications. 7. Trademarks and Copyrighted Material. Customer warrants that it has the right to use any applicable trademarks or copyrighted material used in connection with this service. 8. Transfer of Agreement. Customer may not assign or transfer this Agreement in whole or in part without the prior written consent of Company. In the event that Customer contemplates whole or partial sale of its business ownership change or change in jurisdiction Customer shall notify Company by mail facsimile or email no less than days prior to the effective date of the event. 9. Termination. Company may terminate this Agreement at its sole discretion upon the occurrence of one or more of the following events. failure to comply with any provisions of this Agreement or the Acceptable Use Policy upon receipt of written notice from Company of said failure appointment of receiver or upon the filing of any application by Customer seeking relief from creditors upon mutual agreement in writing of Company and Customer.

9. 1. Account Deactivation Termination or Cancellation. Upon account deactivation termination or deletion all files and data stored on Company servers will be immediately deleted immediately. Company has no obligation or responsibility to store Customers data after Customers account has been deactivated or terminated. 10. Disputes. If legal proceedings are commenced to resolve dispute arising out of or relating to this Agreement the prevailing party shall be entitled to recover all costs legal fees and expert witness fees as well as any costs or legal fees in connection with any appeals. 11. Indemnification. Customer shall indemnify and hold Company harmless from and against any and all claims judgments awards costs expenses damages and liabilities including reasonable attorney fees of whatsoever kind and nature that may be asserted granted or imposed against Company directly or indirectly arising from or in connection with Customers marketing or support services of the product or services or the unauthorized representation of the product and services or any breach of this Agreement by Customer. 12. General. If any provision of this Agreement is held to be unenforceable the enforceability of the remaining provisions shall in no way be affected or impaired thereby. This Agreement shall be governed by and construed in accordance with the laws of the State of state or province. Exclusive jurisdiction and venue shall be in the county County state or province Superior Court. failure by any party to exercise or delay in exercising right or power conferred upon it in this Agreement shall not operate as waiver of any such right or power.

The parties represent and warrant that on the date first written above they are authorized to enter into this Agreement in its entirety and duly bind their respective principals by their signatures below. EXECUTED as of the date first written above. company name By signator authorized signature or signer. Job title of signator authorized signature or signer. Date when the contact was signed

company name By signator authorized signature or signer. Job title of signator authorized signature or signer. Date when the contact was signed Customer Initials Company Initials

How do you write a General Project Work Order (With Deposit) document? (alternate or related contract document)

WORK ORDER company name address address city state or province zip or postal code Phone phone number DATE. current date Order WorkOrder Bill To. company name city state or province zip or postal code

Phone phone number For. Insert what you are doing for the customer here DESCRIPTION* HOURS RATE AMOUNT TOTAL DEPOSIT REQUIRED Agreements In consideration of the mutual covenants set forth in this Agreement Customer and Company hereby agree as follows. 1. Development of Project or Services. Customer agrees to engage Company to develop the Project as described above*. 2. Delivery of Project or Services. Company will use reasonable diligence in the development of the project and endeavor to deliver to Customer an operational project no later than delivery date. Customer acknowledges however that this delivery deadline is an estimate and not required delivery date. 3. Ownership Rights. Company shall hold all right title and interest in and to all copyrights patents trade secrets and other intellectual or industrial property rights in the project or any component or characteristic thereof which are proprietary to the Company. Customer shall not do anything that may infringe upon or in any way undermine Companys right title and interest in the project as described in this paragraph 3. Notwithstanding the above Customer shall retain all of its intellectual property rights in any components it owns and transmits to Company for use in the project. 4. Compensation. For all of Companys services under this Agreement Customer shall compensate the Company in cash the amount specified in the total above. In the event Customer fails to make any of the payments referenced by the deadline set forth as invoiced Company has the right but is not obligated to pursue any or all of the following remedies. terminate the Agreement remove the project from public access bring legal action. 5. Limited Warranty and Limitation on Damages. Developers warrant the project will conform to the Specifications. If the project does not conform to the Specifications the Company shall be responsible to correct the project without unreasonable delay at the Companys sole expense and without charge to Customer to bring the project into conformance with the Specifications. This warranty shall be the exclusive warranty available to the Customer. Customer waives any other warranty express or implied. Customer acknowledges that the Company does not warrant that the project will work on all platforms. Customer acknowledges that the Company is not responsible for the results obtained by the Customer. Should the Customer cancel quit or otherwise terminate the project for any reason Company reserves the full and exclusive right to apply any monies received from the Customer against the Customers outstanding invoice or bill. Customer waives any claim for damages direct or indirect and agrees that its sole and exclusive remedy for damages either in contract or tort is the return of the consideration paid to the Company. 6. Binding Effect. This Agreement shall be binding upon and inure to the benefit of Customer and the Company and their respective successors and assigns provided that the Company may not assign any of its obligations under this Agreement without prior written consent of Customer. ACCEPTANCE OF AGREEMENT. The above prices specifications and conditions are hereby accepted. The Company is authorized to execute the project as outlined in this Agreement. Payment will be made as proposed above. company name

By signator authorized signature or signer. Job title of signator authorized signature or signer. Date when the contact was signed company name By signator authorized signature or signer.

Job title of signator authorized signature or signer. Date when the contact was signed Customer Initials Company Initials

How to write my Project Development Short Form Contract document (alternate or related contract document)

company name Work Order address address city state or province zip or postal code Phone phone number DATE. current date

Order WorkOrder Bill To. company name city state or province zip or postal code Phone phone number For. What you are doing for the customer here

DESCRIPTION HOURS RATE AMOUNT TOTAL Agreements In consideration of the mutual covenants set forth in this Agreement Customer and Developers hereby agree as follows. 1. Development of Web Site Digital Media. Developers agree to develop the Web Site and other Digital Media according to the terms expressed by the customer and recommended by the developers. 2. Delivery of Web Site Digital Media. Developers will use reasonable diligence in the development of the Web Site and endeavor to deliver to Customer an operational Web Site no later than delivery date. Customer acknowledges however that this delivery deadline and the other payment milestones listed in Section are estimates and are not required delivery dates. 3. Ownership Rights. Developers shall hold all right title and interest in and to the Web Site Media. Specifically but without limitation Developer shall hold all right title and interest in and to all text graphics animation audio components and digital components of the Web Site the Content all interfaces navigational devices menus menu structures or arrangements icons help and other operational instructions and all other components of any source or object computer code that comprises the Web Site all literal and non literal expressions of ideas that operate cause create direct manipulate access or otherwise affect the Content and all copyrights patents trade secrets and other intellectual or industrial property rights in the Web Site or any component or characteristic thereof. Customer shall not do anything that may infringe upon or in any way undermine Developers right title and interest in the Web Site as described in this paragraph 3. Notwithstanding the above Customer shall retain all of its intellectual property rights in any text images or other components it owns and transmits to Developers for use in the Web Site. 4. Compensation. For all of Developers services under this Agreement Customer shall compensate Developers in cash the amount specified in the total above. In the event Customer fails to make any of the payments referenced by the deadline set forth in Exhibit Invoice Developers have the right but are not obligated to pursue any or all of the following remedies. terminate the Agreement remove the Web Site and or Digital Media bring legal action. 5. Limited Warranty and Limitation on Damages. Developers warrant the Web Site will conform to the Specifications. If the Web Site does not conform to the Specifications Developers shall be responsible to correct the Web Site without unreasonable delay at Developers sole expense and without charge to Customer to bring the Web Site into conformance with the Specifications. This warranty shall be the exclusive warranty available to the Customer. Customer waives any other warranty express or implied. Customer acknowledges that Developers do not warrant that the Web Site will work on all platforms. Customer acknowledges that Developers are not responsible for the results obtained by the Customer on the Web Site. Customer waives any claim for damages direct or indirect and agrees that its sole and exclusive remedy for damages either in contract or tort is the return of the consideration paid to Developers as set forth in Exhibit attached hereto. 6. Binding Effect. This Agreement shall be binding upon and inure to the benefit of Customer and Developers and their respective successors and assigns provided that Developers may not assign any of his obligations under this Agreement without Customers prior written consent. ACCEPTANCE OF AGREEMENT. The above prices specifications and conditions are hereby accepted. The designer is authorized to execute the project as outlined in this agreement. Payment will be made as proposed above. Customers signature Designers signature Date THANK YOU FOR YOUR BUSINESS.

Writing the Exhibit A (Payment Terms) document (alternate or related contract document)

Select an appropriate payment terms from the list of possible choices depending on the agreement being used with and delete the rest. For example if using project development contract use one of the first three milestone based payment terms. If using VAR Reseller contract or for general pricing use the payment terms pricing plan at the end of the list of plans below. EXHIBIT A PAYMENT TERMS 1. Customer agrees to pay Developers fee of Insert Total Payment Amount according to the following terms. A. 90% of the estimated price upon execution of the Agreement. 2. Customer agrees to the pay for all out of pocket expenses incurred by Developers in developing the project including but without limitation any. A. License fees B. Outsource services billed for Customer

C. Film and Developing D. Shipping E. Domain name registration F. Host costs for ISP G. Hardware and software H. Travel 3. Customer agrees to pay for the Developers fee and all expenses as set forth above within days of invoice. All unpaid balances shall accrue interest at 2% per month. 4. Customer agrees that any changes customer makes to the specification may adversely affect the original estimate. Extra time incurred above and beyond the original specification will be billed at an hourly rate of hourly rate and is not subject to the costs estimates and caps in 1. above.

5. Customer agrees that estimated yearly maintenance costs are only estimates and are not included in the quoted price. EXHIBIT A PAYMENT TERMS 1. Customer agrees to pay Developers fee of Insert Total Payment Amount according to the following terms. A. 3 of the fee upon execution of the Agreement; B. 3 of the fee upon completion of Insert Key Payment Milestone C. The remaining upon completion per the specification. 2. Customer agrees to the pay for all out of pocket expenses incurred by Developers in developing the project including but without limitation any. A. License fees

B. Outsource services billed for Customer C. Film and Developing D. Shipping E. Domain name registration F. Host costs for ISP G. Hardware and software H. Travel 3. Customer agrees to pay for the Developers fee and all expenses as set forth above within days of invoice. All unpaid balances shall accrue interest at 2% per month.

4. Customer agrees that any changes customer makes to the specification may adversely affect the original estimate. Extra time incurred above and beyond the original specification will be billed at an hourly rate of hourly rate and is not subject to the costs estimates and caps in 1. above. 5. Customer agrees that estimated yearly maintenance costs are only estimates and are not included in the quoted price. EXHIBIT A PAYMENT TERMS 1. Customer agrees to pay Developers an hourly fee according to the following terms. A. 10% of the estimate upon execution of the Agreement of Insert Total Payment Amount B. Customer is billed at hourly rate per hour at the completion of each milestone.

C. The customer will not be liable for more than Insert Maximum Amount Liable for in hourly work. 2. Customer agrees to the pay for all out of pocket expenses incurred by Developers in developing the project including but without limitation any. A. License fees B. Outsource services billed for Customer C. Film and Developing D. Shipping E. Domain name registration F. Host costs for ISP

G. Hardware and software H. Travel 3. Customer agrees to pay for the Developers fee and all expenses as set forth above within days of invoice. All unpaid balances shall accrue interest at 2% per month. 4. Customer agrees that any changes customer makes to the specification may adversely affect the original estimate. Extra time incurred above and beyond the original specification will be billed at an hourly rate of hourly rate and is not subject to the costs estimates and caps in 1. above. 5. Customer agrees that estimated yearly maintenance costs are only estimates and are not included in the quoted price. EXHIBIT A CREDIT CARD PAYMENT PLAN Authorization for credit card payments for development per Exhibit and B. Charges to be applied as Customer accepts each milestone. Customer accepts liability for all costs incurred including but not limited to chargebacks and reversals.

Card Number Expiration Date Name on Card Title Phone. phone number Fax. fax number Email. email address

Company. company name Street. address address City. city Country. country EXHIBIT A PAYMENT TERMS Pricing Plan.

Insert your pricing plan here. Discounts. Insert any discounts available here. Restrictions. Insert any restrictions here.

A Document from Contract Pack

The editable Data Backup and Storage Contract template - complete with the actual formatting and layout is available in the retail Contract Packs.

Proposal Kit on FacebookFacebook
Proposal Kit on PinterestPinterest
Proposal Kit on Google+Google+
Proposal Kit on TwitterTwitter
Proposal Kit RSS FeedRSS
Proposal Kit NewsletterNewsletter