How to write my Video and Multimedia Production Contract document

VIDEO MULTIMEDIA PRODUCTION CONTRACT THIS AGREEMENT is made this current day day of current month current year by and between company name Producers and company name Customer Terms and Agreements In consideration of the mutual covenants set forth in this Agreement Customer and Producers hereby agree as follows. 1. Description of the Project Specifications Producers agree to develop the Project according to the terms listed on Exhibit attached hereto. 2. Responsibility for Original Material. Materials provided to Producers for use in fulfilling the Project the Materials may include but are not limited to. Pictures Film Slides mm and 16 mm Film Videotapes Audio Artwork Motion Graphics 3D Animation Digital Media or other source materials required for inclusion in the Project. Producers are not responsible for lost or damaged materials and any compensation due Customer shall extend only to the cost of replacing the Materials in their raw or stock format. Services provided to Customer under this Agreement may include the use of sub contractors and third party services. Customer agrees to indemnify and hold Producers harmless from any and all claims for any loss damage or delay to the Materials or Project while in transit or in the possession of third party services or sub contractors and agrees that damages shall be limited to replacement or replacement cost of the raw original material and media provided to Producers. 3. Delivery of Project.

Producers will use all reasonable efforts in the development of the Project and endeavor to complete and deliver to Customer the completed Project no later than delivery date by an approved party provided that payment and all requested materials and instructions have been received by Producers from Customer. Any delay in the completion of the Project due to actions or negligence of Customer transportation delays illness or circumstances outside the control of Producers shall alter the delivery date. Producers will make reasonable effort to notify Customer of any delays to the estimated delivery date as soon as possible. 3 Proofing. Proofs will be presented for Customer approval at each stage of development. If revisions are required request must be made when proofs are returned to Producers. Reasonable edits based upon Customers feedback will constitute acceptable delivery unless otherwise agreed upon in writing by both Producers and Customer. The total number of proofs provided to Customer shall number Insert Number of Proofs Count unless otherwise determined in the Specifications. Proofs may be provided to Customer in formats that differ from the final output as outlined in the Specifications. Customer acknowledges that colors printing quality media type or any other element presented in the proof to Customer may change upon final delivery and shall not constitute breach or material deviation from the Specifications. 3 Additional Editing and Changes. Any requested changes to the Specifications shall constitute additional editing and incur additional charges or fees. Additional charges for editing and changes shall be billed at hourly rate per hour. All additional changes must be submitted and approved by both parties in writing by approved Contract Change form. 3 Back ups and copies of Project Files.

Producers shall not be responsible for maintaining any copies of Project source files masters materials or other media created by Producers for Customer under this Agreement after any such materials have been turned over to Customer. It is Customers sole responsibility to create back up copies of any Project files received in order to preserve the integrity of their Project files and protect against unforeseen loss. 3 Reproduction of Project. Check all that apply Upon successful completion of all compensation terms and outstanding balances owed to Producers Customer is granted full and unlimited reproduction rights to the Project. Customer is granted one time limited use reproduction right for the Project in exchange for the compensation paid to Producers. Project shall not be reproduced in any format without the written consent of Producers. Producers retains the right to reproduce the Project in any form for marketing future publications competitions or other promotional uses. Producers shall at no time reproduce the Project for use in commercial means or for profit use. 4. Ownership of Masters Media and Source Files.

and so on...

A Document from Contract Pack

The editable Video and Multimedia Production Contract template - complete with the actual formatting and layout is available in the retail Contract Packs.

New 2014 Editions
Proposal Software Help

Pin this Video and Multimedia Production ContractVideo and Multimedia Production Contract : filmView Video and Multimedia Production Contract

Proposal Kit Professional
Proposal Kit TestimonialContract Pack

Professional has helped me from the beginning. It doesn’t matter whether we have a client that is a family friend or a brand new client; we always send them a contract. It is so important to act professional from the beginning."

Proposal Kit TestimonialsOver 500 Proposal Kit testimonials!
Contract Packs with the Video and Multimedia Production Contract document

Document Length: 5 Pages

Usage: For video media production

The Video and Multimedia Production Contract is intended for use when you are providing video production services for a client (web video clips, TV commercials, DVD's, etc.), either as a complete stand-alone project or for inclusion in a larger project. This agreement also includes specific protections for the client to prevent video from being leaked prematurely to the public for sensitive material.

 

Product name: Proposal Kit Professional

Produced by: Proposal Kit

Category: Software > Computer Software > Business & Productivity Software

Price: $197


Proposal Kit reviews4.9 stars, based on 587 reviews
Legal Contract Templates

Alternate documents are those which may be used instead of this document depending on your situation. Alternate documents may be better suited for different size projects, more specialized projects, variations on rights, etc.

Alternate Documents:

Related documents may be used in conjunction with this document depending on your situation. Many related documents are intended for use as part of a contract management system.

Related Documents:
Video and Multimedia Production Contract
Disclaimers:

Cyber Sea, Inc. makes no warranty and accepts no responsibility for suitability of any materials to licensees business. Cyber Sea, Inc. assumes no responsibility or liability for errors or inaccuracies. Licensee accepts all responsibility for results obtained. Information included is not legal advice. Use of any supplied materials constitutes acceptance and understanding of these disclaimers.

Ian Lauder has been helping businesses write their proposals and contracts for over a decade. Ian is the Owner and Founder of Proposal Kit, one of the original sources of business proposal and contract software products started in 1997.

Proposal Kit Produced
By Ian Lauder

How do you write a Video and Multimedia Production Contract document?

VIDEO MULTIMEDIA PRODUCTION CONTRACT THIS AGREEMENT is made this current day day of current month current year by and between company name Producers and company name Customer Terms and Agreements In consideration of the mutual covenants set forth in this Agreement Customer and Producers hereby agree as follows. 1. Description of the Project Specifications Producers agree to develop the Project according to the terms listed on Exhibit attached hereto. 2. Responsibility for Original Material. Materials provided to Producers for use in fulfilling the Project the Materials may include but are not limited to. Pictures Film Slides mm and 16 mm Film Videotapes Audio Artwork Motion Graphics 3D Animation Digital Media or other source materials required for inclusion in the Project. Producers are not responsible for lost or damaged materials and any compensation due Customer shall extend only to the cost of replacing the Materials in their raw or stock format. Services provided to Customer under this Agreement may include the use of sub contractors and third party services. Customer agrees to indemnify and hold Producers harmless from any and all claims for any loss damage or delay to the Materials or Project while in transit or in the possession of third party services or sub contractors and agrees that damages shall be limited to replacement or replacement cost of the raw original material and media provided to Producers. 3. Delivery of Project.

Producers will use all reasonable efforts in the development of the Project and endeavor to complete and deliver to Customer the completed Project no later than delivery date by an approved party provided that payment and all requested materials and instructions have been received by Producers from Customer. Any delay in the completion of the Project due to actions or negligence of Customer transportation delays illness or circumstances outside the control of Producers shall alter the delivery date. Producers will make reasonable effort to notify Customer of any delays to the estimated delivery date as soon as possible. 3 Proofing. Proofs will be presented for Customer approval at each stage of development. If revisions are required request must be made when proofs are returned to Producers. Reasonable edits based upon Customers feedback will constitute acceptable delivery unless otherwise agreed upon in writing by both Producers and Customer. The total number of proofs provided to Customer shall number Insert Number of Proofs Count unless otherwise determined in the Specifications. Proofs may be provided to Customer in formats that differ from the final output as outlined in the Specifications. Customer acknowledges that colors printing quality media type or any other element presented in the proof to Customer may change upon final delivery and shall not constitute breach or material deviation from the Specifications. 3 Additional Editing and Changes. Any requested changes to the Specifications shall constitute additional editing and incur additional charges or fees. Additional charges for editing and changes shall be billed at hourly rate per hour. All additional changes must be submitted and approved by both parties in writing by approved Contract Change form. 3 Back ups and copies of Project Files.

Producers shall not be responsible for maintaining any copies of Project source files masters materials or other media created by Producers for Customer under this Agreement after any such materials have been turned over to Customer. It is Customers sole responsibility to create back up copies of any Project files received in order to preserve the integrity of their Project files and protect against unforeseen loss. 3 Reproduction of Project. Check all that apply Upon successful completion of all compensation terms and outstanding balances owed to Producers Customer is granted full and unlimited reproduction rights to the Project. Customer is granted one time limited use reproduction right for the Project in exchange for the compensation paid to Producers. Project shall not be reproduced in any format without the written consent of Producers. Producers retains the right to reproduce the Project in any form for marketing future publications competitions or other promotional uses. Producers shall at no time reproduce the Project for use in commercial means or for profit use. 4. Ownership of Masters Media and Source Files.

Except for Customers Proprietary Material contained in the Project Producers shall hold all right title and interest in all original artwork whether in draft mock up concept or final development for the Project. Customer hires Producers to make videotape CD ROM DVD or audio transfer for commercial use. All edited video CD ROMs audio and DVD will be subject to copyright by Producers. Any unauthorized copying is strictly prohibited. All equipment supplies cameras edited or master media or any original media produced during the execution of this Agreement shall remain the exclusive property of Producers. 5. Compensation. In return for the Projects that are completed and delivered under this Agreement and Exhibit Customer shall compensate Producers pursuant to the terms of Exhibit attached hereto. In the event Customer fails to make any of the payments referenced in Exhibit by the deadline set forth in Exhibit Producers have the right but are not obligated to pursue any or all of the following remedies. terminate the Agreement withhold all files artwork source commitments or any other service to be performed by Producers for Customer bring legal action. Customer is responsible for all third party material costs as outlined in Exhibit and accepts responsibility for all additional approved costs that Producers may incur in the development of this Project. All masters film tapes or other source materials shall remain the exclusive property of Producers and will only be made available to Customer for an additional fee. 6. Confidentiality. Customer and Producers acknowledge and agree that the Specifications and all other documents and information related to the development of the Project excluding however Customers Proprietary Material the Confidential Information will constitute valuable trade secrets of Producers. Customer shall keep the Confidential Information in confidence and shall not at any time during or after the term of this Agreement without Producers prior written consent disclose or otherwise make available to anyone either directly or indirectly all or any part of the Confidential Information at any time. Producers will not make any of the Project materials whether in part or in whole available to the public domain or any third party not authorized by Customer prior to obtaining written release from Customer or verification that the Project materials have been made available to the public by the Customer. Note For time sensitive materials or releases both parties are encouraged to put schedule of this information in Exhibit the Specifications. 7. Limited Warranty and Limitation on Damages. Producers warrant the Project will conform to the Specifications. If the Project does not conform to the Specifications Producers shall be responsible for the timely correction of the Project at Producers sole expense and without charge to Customer in order to bring the Project into conformance with the Specifications. This warranty shall be the exclusive warranty available to Customer. Customer waives any other warranty express or implied. Customer acknowledges that Producers is not responsible for the results obtained by Customers use of any part of the Project. Customer acknowledges that Producers are not responsible for fixing problems on the Project once mass produced or after Customer has tested proofed and approved the Project Sign off in writing. Except as otherwise expressly stated herein Customer waives any claim for damages direct or indirect and agrees that its sole and exclusive remedy for damages either in contract or tort is the return of the consideration paid to Producers as set forth in Exhibit attached hereto. All Master Tape or other source material created for the Project shall be stored at Producers facilities for year from the date of this Agreement. Producers reserve the exclusive right to destroy delete or otherwise dispose of any materials whether Customer provided or not that are still in Producers possession after year from the date of this Agreement. Original materials provided to Producers by Customer shall be returned upon successful completion of the Project or to the last known good address for Customer. 8. Independent Contractor.

Producers will be retained as independent contractors for the length of this Agreement. Producers will be fully responsible for payment of their own income taxes on all compensation earned under this Agreement. Customer will not withhold or pay any income tax social security tax or any other payroll taxes on Producers behalf. Producers understand that they will not be entitled to any fringe benefits that Customer provides for its employees generally or to any statutory employment benefits including without limitation workers compensation or unemployment insurance. 9. Materials Logos Graphics and other Collateral. Customer agrees to make available to Producers for Producers use in performing the services required by this Agreement such graphical elements and materials as Customer and Producers may agree in writing for such purpose. Failure to provide Producers with Materials in the requested formats may result in additional delays or fees in addition to those stated in Exhibit A. 10. General Provisions. 10 Entire Agreement.

This Agreement contains the entire Agreement between the parties relating to the subject matter hereof and supersedes any and all prior Agreements or understandings written or oral between the parties related to the subject matter hereof. No modification of this Agreement shall be valid unless made in writing and signed by all of the parties hereto. 10 Governing Law. This Agreement shall be governed by and construed in accordance with the laws of the State of state or province. Exclusive jurisdiction and venue shall be in the county County state or province Superior Court. 10 Binding Effect. This Agreement shall be binding upon and enure to the benefit of Customer and Producers and their respective successors and assigns provided that Producers shall not assign any of their obligations under this Agreement without Customers prior written consent. 10 Waiver. The waiver by either party of any breach or failure to enforce any of the terms and conditions of this Agreement at any time shall not in any way affect limit or waive such partys right thereafter to enforce and compel strict compliance with every term and condition of this Agreement.

10 Good Faith. Each party represents and warrants to the other that such party has acted in good faith and agrees to continue to so act in the negotiation execution delivery performance and any termination of this Agreement. 10 No Right to Assign. Customer has no right to assign sell modify or otherwise alter the Project except upon the express written advance approval of Producers unless otherwise noted in Section 3. 2. 10 Payment Milestones. In the event Customer fails to make any of the payments set forth on Exhibit within the time prescribed in Exhibit Producers have the right to immediately cease all work on the Project until payment in full is paid. 10 Indemnification.

Customer warrants that everything it gives Producers to put on the Project is legally owned or licensed to Customer. Customer agrees to indemnify and hold Producers harmless from any and all claims brought by any third party relating to any aspect of the Project including but without limitation any and all demands liabilities losses costs and claims including attorneys fees arising out of injury caused by Customers products services material supplied by Customer copyright infringement and defective products sold via the Project. 10 Use of Project for Promotional Purposes. Customer grants Producers the right to use the Project for promotional purposes and or to cross link it with other marketing venues developed by Producers unless otherwise restricted in the Specifications. 10. 10 Right to Style or to Make Derivative Works. Subject to Section above Producers have the exclusive rights in making any derivative similar works of the Project and any similarities between Customers project and future projects constitutes Producers methods and style and shall remain the right of Producers. 10. 11 Attorneys Fees. In the event any party to this Agreement employs an attorney to enforce any of the terms of the Agreement the prevailing party shall be entitled to recover its actual reasonable attorneys fees and reasonable associated costs including expert witness fees.

How to write my Project Development Short Form Contract document (alternate or related contract document)

company name Work Order address address city state or province zip or postal code Phone phone number DATE. current date

Order WorkOrder Bill To. company name city state or province zip or postal code Phone phone number For. What you are doing for the customer here

DESCRIPTION HOURS RATE AMOUNT TOTAL Agreements In consideration of the mutual covenants set forth in this Agreement Customer and Developers hereby agree as follows. 1. Development of Web Site Digital Media. Developers agree to develop the Web Site and other Digital Media according to the terms expressed by the customer and recommended by the developers. 2. Delivery of Web Site Digital Media. Developers will use reasonable diligence in the development of the Web Site and endeavor to deliver to Customer an operational Web Site no later than delivery date. Customer acknowledges however that this delivery deadline and the other payment milestones listed in Section are estimates and are not required delivery dates. 3. Ownership Rights. Developers shall hold all right title and interest in and to the Web Site Media. Specifically but without limitation Developer shall hold all right title and interest in and to all text graphics animation audio components and digital components of the Web Site the Content all interfaces navigational devices menus menu structures or arrangements icons help and other operational instructions and all other components of any source or object computer code that comprises the Web Site all literal and non literal expressions of ideas that operate cause create direct manipulate access or otherwise affect the Content and all copyrights patents trade secrets and other intellectual or industrial property rights in the Web Site or any component or characteristic thereof. Customer shall not do anything that may infringe upon or in any way undermine Developers right title and interest in the Web Site as described in this paragraph 3. Notwithstanding the above Customer shall retain all of its intellectual property rights in any text images or other components it owns and transmits to Developers for use in the Web Site. 4. Compensation. For all of Developers services under this Agreement Customer shall compensate Developers in cash the amount specified in the total above. In the event Customer fails to make any of the payments referenced by the deadline set forth in Exhibit Invoice Developers have the right but are not obligated to pursue any or all of the following remedies. terminate the Agreement remove the Web Site and or Digital Media bring legal action. 5. Limited Warranty and Limitation on Damages. Developers warrant the Web Site will conform to the Specifications. If the Web Site does not conform to the Specifications Developers shall be responsible to correct the Web Site without unreasonable delay at Developers sole expense and without charge to Customer to bring the Web Site into conformance with the Specifications. This warranty shall be the exclusive warranty available to the Customer. Customer waives any other warranty express or implied. Customer acknowledges that Developers do not warrant that the Web Site will work on all platforms. Customer acknowledges that Developers are not responsible for the results obtained by the Customer on the Web Site. Customer waives any claim for damages direct or indirect and agrees that its sole and exclusive remedy for damages either in contract or tort is the return of the consideration paid to Developers as set forth in Exhibit attached hereto. 6. Binding Effect. This Agreement shall be binding upon and inure to the benefit of Customer and Developers and their respective successors and assigns provided that Developers may not assign any of his obligations under this Agreement without Customers prior written consent. ACCEPTANCE OF AGREEMENT. The above prices specifications and conditions are hereby accepted. The designer is authorized to execute the project as outlined in this agreement. Payment will be made as proposed above. Customers signature Designers signature Date THANK YOU FOR YOUR BUSINESS.

How to write my Contract Milestone Acceptance Signoff Form document (alternate or related contract document)

company name Milestone Acceptance Signoff address address city state or province zip or postal code Phone phone number DATE. current date Order WorkOrder Client. company name

city state or province zip or postal code Phone phone number For. General Description of Project Deliverable Please initial the following sections which detail the project deliverable contracted between company name and company name and sign the Acceptance of Agreement at the bottom of this page. Initials Description of Completed Milestone Acceptance of Milestone Insert Milestone number here Milestone description here ACCEPTANCE OF AGREEMENT. I certify that have received the above project deliverable from company name and that the deliverable listed above has been demonstrated delivered or otherwise completed to my satisfaction. Clients signature

How to write my Project Copyright Transfer Contract document (alternate or related contract document)

TRANSFER OF COPYRIGHT AGREEMENT THIS AGREEMENT is made this current day day of current month current year by and between company name hereafter referred to as Author and company name hereafter referred to as Client PART A. The purpose of this Agreement hereafter referred to as the Agreement is to act as transfer of copyright for the attached work Exhibit hereafter referred to as the Article from company name to company name effective as of the date of this agreement. Note. If article was prepared as part of the writers duties for his her employer work for hire this agreement must be signed and authorized by the employer as the Author. If the Article was prepared by U. S. Government employee as part of his her official duties please refer to Part B.

Copyright to the above work including without limitation the right to publish the work in whole or in part in any and all forms of media now or hereafter known is hereby transferred to company name for the following publication uses. Insert details of the specified usage of the content. Copyright to the listed original and unpublished article and subsequent revisions errata or abstracts submitted by the above author the Article is hereby transferred to company name for the full term thereof throughout the world subject to the following rights that the author may freely exercise and to acceptance of the Article for publication and use in company name business. company name shall have the right to register as claimant copyright to the Article in its name whether used individually or as part of another work or medium in which the Article is part of. The author shall retain the following rights so long as the author agree that all copies of the Article made under any of these following rights shall include notice of the company name copyright. 1 All proprietary rights and patent rights other than copyright and the publication rights transferred to company name.

2 The nonexclusive right after publication by company name to give permission to third parties to republish the Article or translation thereof or excerpts therefrom without obtaining permission from company name provided the company name published version is not used for this purpose and provided the Article is not to be published in another journal or web site. If the company name version is used permission from company name must be obtained. 3 The right to post their own author versions of reprints and revisions to use all or part of the Article without revision or modification including the company name published version in personal collection or other publications of the authors own works so long as the company name copyright notice is attached. 4 The right of an employer to make copies of the Article so long as it was prepared by an employee within the scope of his or her employment and only for the employers own internal use. 5 In the case of work performed under United States Government contract Publisher grants the U. S. Government royalty free permission to reproduce all or portions of the Article and to authorize others to do so for U. S. Government purposes. In the event that the Article is not accepted and published by company name this agreement becomes null and void. By signing this Agreement the author warrants that the Article is original with the author and does not infringe any copyright or violate any other right of any third parties and that the Article has not been published elsewhere and is not being considered for publication elsewhere in any form except as provided herein. If each authors signature does not appear below the signing author represent that they sign this Agreement as authorized agents for and on behalf of all the authors and that this Agreement and authorization is made on behalf of all the authors. The signing author or in the case of work made for hire the signing employer also warrant that they have the full power to enter into this Agreement and to make the grants contained herein. If any provision of this agreement is held to be unenforceable the enforceability of the remaining provisions shall in no way be affected or impaired thereby. This agreement and any disputes arising here under shall be governed by the laws of state or province state without regard to conflicts of laws principles. failure by any party to exercise or delay in exercising right or power conferred upon it in this agreement shall not operate as waiver of any such right or power.

company name Name. Signature. Date. PART B. In the case of work that was performed under U. S. Government contract but you are not U. S. Government employee please sign the transfer form above and review Item above. The following certifies that the author of the listed Article see Exhibit are employees of the U. S. Government and the work was performed as part of their employment and that the Article is not subject to protection under U. S. Copyright. Name. Signature.

Govt. Organization. Date. Author Initials Client Initials

A Document from Contract Pack

The editable Video and Multimedia Production Contract template - complete with the actual formatting and layout is available in the retail Contract Packs.

Proposal Kit on FacebookFacebook
Proposal Kit on PinterestPinterest
Proposal Kit on Google+Google+
Proposal Kit on TwitterTwitter
Proposal Kit RSS FeedRSS
Proposal Kit NewsletterNewsletter