Order today for free lifetime support & 2 years upgrades - Limited Time Offer
This contract document is also included in the discounted Proposal Kit Professional bundle. Order and download for $199.
The Project Acceptance Simple Signoff Form is used for the client and developer to sign off on the final acceptance of the project. Use this form when the project is complete and both parties agree that the project conforms to the terms of the contract. This is a short form version.
Document Length: 1 Page
Business proposal example It taught me

one basic lesson, the big boys like paperwork and they are willing to pay big money when things are presented correctly, they were impressed with the proposals, which in my mind "Proposal Kit" signed the deal for me! To be very honest, I have never made so much money so easily."

Glyn Carnell
The actual document is delivered in the retail products as an editable template.
Produced by:
Proposal Kit
Category:
Software > Computer Software > Business & Productivity Software
Price:
$199 USD
 
 
Proposal Kit reviews4.9 stars, based on over 700 reviews
Alternate documents are those which may be used instead of this document depending on your situation. Alternate documents may be better suited for different size projects, more specialized projects, variations on rights, etc.

Alternate Documents:
Project Acceptance Simple Signoff
Disclaimers: Proposal Kit, Inc. makes no warranty and accepts no responsibility for suitability of any materials to licensees business. Proposal Kit, Inc. assumes no responsibility or liability for errors or inaccuracies. Licensee accepts all responsibility for results obtained. Information included is not legal advice. Use of any supplied materials constitutes acceptance and understanding of these disclaimers.

Writing the Project Acceptance Simple Signoff document

company name Project Acceptance Simple Signoff address address city state or province zip or postal code Phone. phone number DATE. current date Order #. WorkOrder

Contract ID. contract reference number Client. company name city state or province zip or postal code Phone phone number For. General Description of Project Deliverables ACCEPTANCE OF AGREEMENT. I certify that have received all project deliverables from company name and that all deliverables have been demonstrated delivered or otherwise completed to my satisfaction. further certify and release company name from any further obligation support or duty concerning this project including any and all continued support services.

I understand that by signing this agreement release company name from any and all liability tort or claim concerning this project its files source code object code programming or other materials whether printed or digital provided to client. further understand that all files provided to me under this or any other agreement are to be used at my sole risk and responsibility and all files should be tested prior to publication or any mass distribution in any format. company name is not responsible for any results obtained from the use of any software materials presentation or products provided to client under this agreement. Clients Signature

How to write my Contract Milestone Acceptance Signoff Form document (alternate or related contract document)

company name Milestone Acceptance Signoff address address city state or province zip or postal code Phone phone number DATE. current date

Order WorkOrder Client. company name city state or province zip or postal code Phone phone number For. General Description of Project Deliverable Please initial the following sections which detail the project deliverable contracted between company name and company name and sign the Acceptance of Agreement at the bottom of this page.

Initials Description of Completed Milestone Acceptance of Milestone Insert Milestone number here Milestone description here ACCEPTANCE OF AGREEMENT. I certify that have received the above project deliverable from company name and that the deliverable listed above has been demonstrated delivered or otherwise completed to my satisfaction. Clients signature

How to write my Project Contract Acceptance Signoff Form (Verbose) document (alternate or related contract document)

company name Project Acceptance Signoff address address city state or province zip or postal code Phone. phone number DATE. current date Order WorkOrder Client. company name

city state or province zip or postal code Phone. phone number For. General Description of Project Deliverables Please initial the following sections which detail the projects deliverables contracted between company name and company name and sign the Acceptance of Agreement at the bottom of this document. Initials Description of Completed Milestone Acceptance of Milestone #1 description here

Acceptance of Milestone #2 description here Acceptance of Milestone #3 description here Acceptance of Milestone #n description here Acceptance of Project per Contract Specifications. ACCEPTANCE OF AGREEMENT.

I certify that have received the above project deliverables from company name and that all deliverables have been demonstrated delivered or otherwise completed to company names satisfaction. further certify and release company name from any further obligation or duty unless otherwise agreed upon in writing. I understand that by signing this agreement release company name from any and all liability tort or claim concerning this project. further understand that all files provided to company name are to be used at company names sole risk and responsibility and all files should be tested prior to sending them to press replication or any other mass production. company name may now charge or invoice company name any outstanding monies owed for completion of the project. Best Practice Note. If billing by credit card the above line should include permission to charge their credit card. This helps reduce your chargeback exposure. Example. Florentine Design Group LLC may now charge the final installment of 390 to AMEX ************345 for completion of the project. Clients signature. Date.

Writing the Project Contract Acceptance Signoff Form document (alternate or related contract document)

company name Project Acceptance Signoff address address city state or province zip or postal code Phone phone number DATE. current date Order WorkOrder

Client. company name city state or province zip or postal code Phone phone number For. General Description of Project Deliverables Please initial the following sections which detail the projects deliverables contracted between company name and company name and sign the Acceptance of Agreement at the bottom of this document. Initials Description of Completed Milestone

Acceptance of Milestone #1 description here Acceptance of Milestone #2 description here Acceptance of Milestone #3 description here Acceptance of Milestone #n description here Acceptance of Project per Contract Specifications. ACCEPTANCE OF AGREEMENT. I certify that have received the above project deliverables from company name and that the deliverables listed above have been demonstrated delivered or otherwise completed to my satisfaction. Best Practice Note. If billing by credit card the above line should include permission to charge their credit card. This helps reduce your chargeback exposure. Example. Florentine Design Group LLC may now charge the final installment of 390 to AMEX ************345 for completion of the project. Clients signature

Writing the Project Acceptance Partial Signoff document (alternate or related contract document)

company name Project Acceptance Signoff address address city state or province zip or postal code Phone. phone number DATE. current date Order #. WorkOrder Client. company name city state or province zip or postal code

Phone phone number For. General Description of Project Deliverables Please initial the following sections which detail the projects deliverables contracted between company name and company name and sign the Acceptance of Agreement at the bottom of this document. Initials Description of Completed Deliverables Project Deliverable Description. Project Deliverable Description. Initials Description of Work Owed to Client Project Deliverable Description. Project Deliverable Description.

ACCEPTANCE OF AGREEMENT. I certify that have received the above project deliverables from company name and that all deliverables have been demonstrated delivered or otherwise completed to my satisfaction. further certify and release company name from any further obligation support or duty concerning this project. I understand that by signing this agreement release company name from any and all liability tort or claim concerning this project its files source code object code programming or other materials whether printed or digital provided to client. further understand that all files provided to me under this or any other agreement are to be used at my sole risk and responsibility and all files should be tested prior to publication or any mass distribution. company name is not responsible for any results obtained from the use of any software materials presentation or products provided to client under this agreement. Clients Signature

How do you write a Open Source Application Development Agreement document? (example of another included contract document)

company name APPLICATION DEVELOPMENT AGREEMENT OPEN SOURCE THIS AGREEMENT is made this current day day of current month current year by and between company name hereafter referred to as Customer and company name hereafter referred to as Company The purpose of this Application Development Agreement is to set forth contract arrangement under which Company will provide Application Development Services Web Site Development Database Development and other assorted Programming Services to Customer. Recitals A. Company has experience and expertise in the development of software applications. B. Customer desires to have Company develop software application for it. C. Company desires to develop Customers software application on the terms and conditions set forth herein the Software Project

Agreements In consideration of the mutual covenants set forth in this Agreement Customer and Company hereby agree as follows. 1. Development of Software Project. Customer agrees to compensate Company according to the terms listed on Exhibit attached hereto. 2. Specifications.

Company agrees to develop the Software Project pursuant to the specifications set forth in Exhibit attached hereto the Specifications 3. Delivery of Software Project. Company will use reasonable diligence in the development of the Software Project and endeavor to deliver to Customer operational Software Project files as soon as possible. Customer acknowledges however that this delivery deadline and the other payment milestones listed in Exhibit are estimates and are not required delivery dates. Company will make every effort to advise Customer of any delays in advance and seek Customer feedback in regard to the proposed timeline as the Development process progresses. 4. Ownership Rights. Customer shall hold all rights title and interest in the Software Project and the Software Project design and content as whole excepting all pre existing works rightfully owned by Company or third party copyright holders. Customer shall hold all rights title and interest to all text graphics animation audio components and digital components of the Software Project. Company shall hold all rights title and interest in all pre existing works interfaces navigational devices menus menu structures or arrangements icons help and other operational instructions and all other components of any source or object computer code that comprises the Software Project all pre existing literal and non literal expressions of ideas Companys Style that operate cause create direct manipulate access or otherwise affect the Software Project and all other pre existing or proprietary copyrights patents trade secrets and other intellectual or industrial property rights in the Software Project or any component or characteristic thereof. Customer shall not do anything that may infringe upon or in any way undermine Companys rights title and interest in the Software Project as described in this paragraph 4. Notwithstanding the above Customer shall retain all of its intellectual property rights in any text images or other components it owns and delivers to Company for use in the Software Project in addition to the physical presence of the site itself. Customer shall be provided with copy of all source code source files and graphic files as part of this Agreement and there shall not be any additional royalty license or other payment required of Customer to Company for the intended use of the Software Project. 5. Web Hosting Services Provided. Company may at its discretion host portions of the Software Project at its own cost to facilitate development and testing of the Software Project.

6. Software Project Development Services Provided. Company will provide development services according to the Specifications attached as Exhibit B. 7. Proprietary Information. Proprietary information exchanged hereunder shall be treated as such by both Company and Customer. This information shall include but not be limited to the provisions of this agreement and both parties product services information and pricing. Customer further agrees to not decompose disassemble decode or reverse engineer any Company owned program code or technology delivered to Customer or any portion thereof. 8. Interference. Company will exercise no control whatsoever over the content of the information passing through any part of the Software Project.

9. Warranty That Software Project Shall Work According to the Specifications. Company warrants that the Software Project will conform to the Specifications and upon written notification of defect or other non conformation to the specification Company will work to bring the Software Project into conformance with the specification at its own cost and in as timely manner as possible. Company is not responsible for defects caused by changes or issues resulting from third party tools or applications it does not have direct control over including but not limited to. web browsers operating systems OS plug ins extensions software programs applets newly discovered vulnerabilities scripts or other items. 9 No Warranty for Outcome or Use of the Software Project. Company makes no warranties or representations of any kind whether expressed or implied for the suitability or the outcome from the use of the service it is providing. Company also disclaims any warranty of merchantability or fitness for any particular purpose and will not be responsible for any damages that may be suffered by Customer including loss of data resulting from delays non deliveries or service interruptions by any cause or errors or omissions. Use of any information or results obtained is at Customers own risk and Company specifically denies any responsibility for the accuracy or quality of information obtained through its services. Any connection speed or application execution speed for end users is not guaranteed. Company specifically denies any responsibilities for any damages arising as consequence of any unavailability. 9 No Warranty for Use of Open Source Software and Solutions. Company makes no warranties or representations of any kind whether expressed or implied for the suitability of any of the Open Source applications solutions components source code whether in part or in whole installed or otherwise utilized in the delivery of the Software Project. Company is not responsible for the maintenance or use of such now or in the future including all upgrades patches and incompatibilities with software and third party applications or any other problem or disruption arising out of the use of Open Source. 10. Intellectual Property. Customer warrants that it has the right to use any applicable trademarks or copyrighted material used in connection with this service. Company warrants that it has the right to use any applicable trademarks service marks or other copyrighted material used by Company in the development and implementation of the Software Project which have not been provided by Company. 10 Open Source Disclaimer.

Customer acknowledges that the solutions being provided by Company are Open Source and Customer is being granted Worldwide non exclusive license under the General Public License GPL to deploy modify or otherwise use the Open Source Code in their business or enterprise. 11. Change of Ownership. In the event that Customer or Company contemplates whole or partial sale of its business ownership change or change in jurisdiction during the course of this Agreement parties shall notify one another by mail facsimile or email no less than days prior to the effective date of the event. 12. Termination. Customer may terminate this Agreement at its sole discretion upon one or more of the following events. failure on the part of Company to comply with any provisions of the Agreement upon receipt of written notice from Customer of said failure appointment of Receiver or upon the filing of any application by Company seeking relief from creditors or upon mutual agreement in writing of Customer and Company. 13. Disputes. If legal proceedings are commenced to resolve dispute arising out of or relating to this agreement the prevailing party shall be entitled to recover all costs legal fees and expert witness fees as well as any costs or legal fees in connection with any appeals. 14. Indemnification. Customer shall indemnify and hold Company harmless from and against any and all claims judgments awards costs expenses damages and liabilities including reasonable attorney fees of whatsoever kind and nature that may be asserted granted or imposed against Company directly or indirectly arising from or in connection with Customers marketing or support services of the product or services or the unauthorized representation of the product and services or any breach of this agreement by Customer. Customer warrants that everything it gives Company to incorporate into the Software Project is legally owned or licensed to Customer. Customer agrees to indemnify and hold Company harmless from any and all claims brought by any third party relating to any aspect of the Software Project including but without limitation any and all demands liabilities losses costs and claims including attorneys fees arising out of injury caused by Customers products services material supplied by Customer copyright infringement and defective products sold via the Software Project.

15. Use of Software Project for Promotional Purposes. Customer grants Company the right to reference the Software Project for promotional purposes and or to cross link to it with other marketing efforts developed by Company. Company may not at any time disclose or grant access to Customers Software Project private information resources or any other non public asset used for the purposes of promotion or marketing. 16. No Responsibility for Theft. Company has no responsibility for any third party taking stealing hacking altering or otherwise modifying all or any part of the Software Project Source Code Object Code Graphics Text data or any other materials related to the Software Project. 17. Right to Make Derivative Works.

Company has exclusive rights in making any derivative works of pre existing or open source code or related graphics and animations. Customer acknowledges that similarities may exist between other Software Projects developed by Company for Customer and any such similarities both past and future constitute Companys artistic style and proprietary information. 18. Identification of Company. Customer agrees that Companys links will be placed on the bottom of the front page and on internal pages of the Software Project in mutually agreeable small type font. Customer also agrees to put Companys copyright notices in any source code where pre existing or proprietary information is present. Source code copyrights shall not be public unless user views the source code directly. Customer agrees to display all legally required copyright notices as prescribed by applicable law. 19. General. If any provision of this Agreement is held to be unenforceable the enforceability of the remaining provisions shall in no way be affected or impaired thereby. failure by any party to exercise or delay in exercising right or power conferred upon it in this Agreement shall not operate as waiver of any such right or power.

20. Governing Law. This Agreement shall be governed by and construed in accordance with the laws of the State of state or province. Exclusive jurisdiction and venue shall be in the county County state or province Superior Court. 21. Force Majeure. Company will not be responsible for fulfilling its obligations under this Agreement if such failure is caused by circumstances beyond the reasonable control of Company or its suppliers or contractors including but not limited to acts of God disasters acts of terrorism unavailability of materials equipment failures strikes riots wars or other labor disturbances. EXECUTED as of the date first written above. company name By signator authorized signature or signer. Job title of signator authorized signature or signer. Date when the contact was signed

company name By signator authorized signature or signer. Job title of signator authorized signature or signer. Date when the contact was signed Customer Initials Company Initials

How to write my Mobile Software Development Contract document (example of another included contract document)

MOBILE SOFTWARE DEVELOPMENT AGREEMENT THIS AGREEMENT is made this current day day of current month current year by and between company name Developers and company name Customer Recitals A. Developers have experience and expertise in the development of Mobile Software Mobile Software B. Customer desires to have Developers develop Mobile Software for it.

C. Developers desire to develop Customers Mobile Software on the terms and conditions set forth in Exhibit attached hereto the Specifications Definitions Deliverables shall mean the Mobile Software provided in object and or source format as set forth in the Specifications and subject to Developers Proprietary Rights documentation or other materials required to be delivered by Developers to Customer as set forth in the Specifications. Critical Deliverables shall mean Deliverables that have Milestone date as outlined in the Specifications that must be transmitted to Customer on or before specific date. Source Code shall mean the readable forms together with make and build files. Beta shall mean any and all Deliverables provided to Customer prior to the Launch Date.

Final shall mean any and all Deliverables provided to Customer that are in accordance with the Specifications and accepted by Customer as completion of particular Deliverable. Launch Date shall mean the date that the Product is first available for use by the public. Mobile Software shall mean the Mobile Software program described in the Specifications that are to be developed by Developers including all Enhancements made under this Agreement. Mobile Device shall mean all hand held touch screen or other portable devices on which the Mobile Software shall operate. full list of such devices shall be contained in Exhibit B. Mobile Browser shall mean device specific browser technology which the Mobile Software shall be displayed on or run from. full list of such devices shall be contained in Exhibit B. Product shall mean Mobile Software for computer or an end user. Schedule shall mean the schedule for completion of the Deliverables as set forth in the Specifications. Delivery shall mean transmitted by Developers to Customers electronically and in accordance with security measures agreed upon by both parties in accordance with the Specifications. Services shall mean any training customization enhancement or other labor performed by Developers as required by the Specifications.

Error shall mean malfunction or defect within the Mobile Software or within Deliverable that prevents that software from conforming to the Specifications. Internet shall mean any system for distributing digital or electronic information to end users via transmission broadcast or any other form of delivery whether direct or indirect known or subsequently developed. Mobile Network shall mean any network in which connection to the Internet is delivered through to Mobile Device. Mobile Plug ins shall mean all software required by Mobile Devices in order to run the Mobile Software. Specifications shall mean the specifications for the Product and Services attached to this Agreement as Exhibit which shall include detailed specifications and instructions for all required Deliverables features and functionality and complete production schedule for each Deliverable and Milestone. Term shall mean the period of time commencing on the Effective Date of this Agreement and continuing indefinitely until this Agreement is terminated. User Interface shall mean all navigational devices menus menu structures or arrangements icons visual mechanisms metaphors or help and other operational instructions and all other components of any source or object computer code that comprises the Mobile Software.

Web shall mean the World Wide Web containing pages written in hypertext markup language HTML and or any similar successor technology. Web Page shall mean any document that may be viewed in its entirety on the Web. Web Site shall mean collection of interrelated Web pages or documents accessible through Web page browser interface or any other similar successor technology. Mobile Site shall mean any collection of interrelated Web Pages or documents which have been specifically created or formatted for Mobile Devices or specifically for the Mobile Software. Developers Proprietary Material shall mean all intellectual property rights in any text images or other components and or materials owned by Developers or which Developers have the legal right to use that are delivered to Customer; including but not limited to Mobile Software related documentation source code scripts object code logos graphics or tag lines.

Customers Proprietary Material shall mean all intellectual property rights in any text images or other components and or materials owned by Customer or which Customer has the legal right to use that are delivered to Developers including but not limited to Mobile Software related documentation Customer marketing material logos graphics or tag lines. Developer Code shall mean all Developers Proprietary Material or Mobile Software Source Code existing as of the date of this Agreement that is to be incorporated into the Source Code of the Product. The license terms for Developer Code will be stated in the Specifications. Documentation shall mean all user guides reference integration installation or implementation manuals that describe in detail the operation of the Mobile Software and which are normally provided by Developer as part of its deliveries to its customers. Development Activities shall mean any activities undertaken by Developer in the development of the Mobile Software and Documentation satisfying the Specifications pursuant to this Agreement. Enhancements shall mean error corrections bug fixes modifications and updates not included in the Specifications with respect to the Mobile Software. Milestone shall mean each development or Deliverable reached by Developers and agreed upon in writing between Developers and Customer. Milestone Payment shall mean payment obligation related to the achievement and acceptance of particular Milestone. Acceptance shall mean completion of Deliverable that conforms to the Specifications and is mutually agreed upon in writing by both Developers and Customer.

Agreements In consideration of the mutual covenants set forth in this Agreement Customer and Developers hereby agree as follows. 1. Development of Mobile Software. Developers agree to complete the installation management documentation and development of the Mobile Software and Mobile Software based operations according to the compensation terms listed on Exhibit attached hereto. 2. Specifications. Developers agree to develop the Mobile Software pursuant to the Specifications set forth in Exhibit attached hereto the Specifications 3. Delivery Dates and Milestones.

Developers will use reasonable diligence in the development of the Mobile Software and endeavor to deliver to Customer operational Mobile Software no later than delivery date. Customer acknowledges however that this delivery deadline and the other payment milestones listed in Exhibit are estimates and are not required delivery dates unless otherwise noted in the Specifications. Deliverables defined as Critical Deliverables shall be outlined in Exhibit and shall contain the delivery date and terms of delivery of the Critical Deliverable. Developers will retain the Source Code for the Mobile Software and provide Customer with the output formats only. The output is to be used only within the scope of the Mobile Software as outlined in Exhibit and does not include the following. replication duplication or otherwise copying the Mobile Software in any form not authorized by Developers; creating new Mobile Software based on the code its functions or other Proprietary Rights as outlined in Paragraph 4; sale or distribution of the code in any form; or any relinquishment of copyright by Developers in any way. 4. Ownership Rights. Except for Customers Proprietary Material defined below contained in the Mobile Software Developers shall hold all rights title and interest in and to the Mobile Software. Specifically but without limitation Developers shall hold all rights title and interest in and to all text graphics animation audio components and digital components of the Mobile Software the Content all interfaces navigational devices menus menu structures or arrangements icons help and other operational instructions and all other components of any source or object computer code that comprise the Mobile Software all literal and nonliteral expressions of ideas that operate cause create direct manipulate access or otherwise affect the Content and all copyrights patents trade secrets and other intellectual or industrial property rights in the Mobile Software or any component or characteristic thereof. Customer shall not do anything that may infringe upon or in any way undermine Developers rights title and interest in the Mobile Software as described in this Paragraph 4. Notwithstanding the above Customer shall retain and Developers shall have no Proprietary Rights whatsoever in all of Customers intellectual property rights in any and all text images or other components and or materials owned by Customer or which Customer has the legal right to use that are delivered to Developers including but not limited to Mobile Software related documentation Customer marketing material logos and tag lines Customers Proprietary Material Developers agree that they shall not use Customers Proprietary Material for any purpose other than those expressly set forth in this Agreement. 5. Mobile Software Development. Mobile Software Development and Services described here are provided for Android iPhone Windows Mobile Sun and Linux Windows Macintosh Sun Solaris UNIX systems only unless otherwise specified. Insert device specific information here. Unless otherwise agreed upon by Developers and Customer any modifications required to the Mobile Software code or other component related to its operation that are result of third party changes to resources required by the Mobile Software shall be considered ADDITIONAL and will fall outside of the Specifications. Third party modifications may include but are not limited to. patches fixes security flaws errors updates upgrades or any other changes to third party operating systems plug ins or any required resources not created by Developers.

6. Specific Enhancements. Developers and Customer acknowledge that at some time during the Term of this Agreement that enhancements to the Mobile Software may be proposed by either Developers or Customer which fall outside of the scope of the Specifications. Upon such proposal Developers shall confer in good faith with Customer concerning the feasibility of developing such enhancements and the time frame for developing testing and incorporating such enhancements. Developers and Customer shall mutually agree in writing as to whether Developers shall pursue the development of such enhancements and if so which party will fund such development. The Specifications will be amended to include such enhancements. 7. Backups and Redundancies for Development. Developers will maintain off site storage of all stages of the Source Code and other backup media related to this Agreement to ensure Mobile Software integrity and protection and will be responsible for setting up daily procedure for backing up all data. Developers agree to update all backups of code on daily basis unless otherwise agreed upon in the Specifications. Backups will be maintained for one year from the acceptance date of the project. 8. Acceptance.

The terms and conditions contained in this Section will apply to the initial release of the Mobile Software as well as to subsequent releases upgrades enhancements or any other versions thereof. Customer shall evaluate any beta or final version of each Deliverable and shall submit an acceptance or rejection to Developers within days days after Customers receipt of an agreed upon transmission of each Deliverable. 9. Testing and Quality Assurance. Developers agree to thoroughly test the Mobile Software Product including without limitation each and every release version and enhancement thereof as appropriate under the circumstances at all appropriate stages of development and shall document their testing by written test documents delivered to Customer. Developers will submit their test plans to Customer including list of all devices the Mobile Software is to be tested on so as to ensure that Customers standards of quality are maintained and Developers agree to subsequently modify the test plans to accommodate Customers requests if Customer reasonably deems this necessary. Quality Assurance or test documentation shall include detailed descriptions of the tests conducted their results and any outstanding or unresolved issues. Developers will not deploy the Product Mobile Software or any enhancement thereof unless Customer and Developers agree upon such action in writing. 10. Adherence to Schedule. If Developers fail to transmit any Critical Deliverable within the dates specified in the Schedule or fail to meet Milestone as defined in the Specifications then Breach of Agreement Breach shall be considered to have occurred. Customer may. amend the Schedule to include correction period; or suspend the Schedule until the problem is corrected at the sole expense of Developers subject to Customers reasonable satisfaction; or terminate this Agreement. Delivery of all Deliverables not defined in the Specifications as Critical Deliverables shall be considered estimates and delivery shall not be subject to Breach. Developers shall not be held responsible for any delays due to milestones missed by Customer delays due to Customer Deliverables or delays due to transmission equipment failure strikes riots disasters or other natural occurrences.

11. Support Services. Developers will be available to respond to Customers questions about Mobile Software and Mobile Software problems. Developers will staff help desk with combination of phone and email support services from 9. am to 5. p. m. Monday through Friday time zone. Developers will be responsible for maintaining an ongoing log of support requests and actions taken and for tracking user support requests to completion. Support relating to Mobile Networks or Mobile Devices may fall on the individual Mobile Network or Mobile Device Manufacturer. 12. Compensation. For all of Developers services under this Agreement Customer shall compensate Developers in cash pursuant to the terms of Exhibit attached hereto. In the event Customer fails to make any of the payments referenced in Exhibit by the deadline set forth in Exhibit Developers have the right but are not obligated to pursue any or all of the following remedies. terminate the Agreement; remove equipment owned by Developers whether leased to Customer by Developers or not and remove any Developers Personnel or Staff from Customer location ; bring legal action; or suspend development of the Mobile Software in which case Customer is responsible for any schedule changes required and additional financial impact. 13. Confidentiality. Customer and Developers acknowledge and agree that the Specifications and all other documents and information related to the development of the Mobile Software the Confidential Information will constitute valuable trade secrets of Developers. Customer shall keep the Confidential Information in confidence and shall not at any time during or after the term of this Agreement without Developers prior written consent disclose or otherwise make available to anyone either directly or indirectly all or any part of the Confidential Information. 14. Limited Warranty and Limitation on Damages. Developers warrant that the Mobile Software will conform to the Specifications. If the Mobile Software does not conform to the Specifications Developers shall be responsible to correct the Mobile Software without unreasonable delay at Developers sole expense and without charge to Customer to bring the Mobile Software into conformance with the Specifications. This warranty shall be the exclusive warranty available to Customer. Customer waives any other warranty express or implied. Customer acknowledges that Developers do not warrant that the Mobile Software will work on all platforms. Customer acknowledges that Developers will not be responsible for the results productivity or any other measurable metric not specified in Exhibit obtained by Customer on the Mobile Software. Customer waives any claim for damages direct or indirect and agrees that its sole and exclusive remedy for damages either in contract or tort is the return of the consideration paid to Developers as set forth in Exhibit attached hereto. Developers will monitor the reliability and stability of the Mobile Software for period of up to days to ensure that it performs in accordance with the Specifications. If modifications are required at any time Developers will confer in good faith with Customer concerning the appropriateness of any modifications and mutually agree whether or not to make such modifications; provided however that such agreement will not be deemed to relieve Developers from their obligations to ensure that the Product continues to conform to the Specifications and compensation estimates as specified in Exhibit A.

15. Independent Contractor. Developers shall be retained as independent contractors. Developers will be fully responsible for payment of their own income taxes on all compensation earned under this Agreement. Customer will not withhold or pay any income tax social security tax or any other payroll taxes on Developers behalf. Developers understand that they will not be entitled to any fringe benefits that Customer provides for its employees generally or to any statutory employment benefits including without limitation workers compensation or unemployment insurance. 16. Equipment. Customer agrees to make available to Developers for Developers use in performing the services required by this Agreement such items of hardware including specific mobile devices or devices run on specific mobile networks and related Mobile Software as Customer and Developers may agree are reasonably necessary for such purpose. detailed list of such equipment requirements shall be included in Exhibit B. 17. General Provisions.

17 Entire Agreement. This Agreement contains the entire agreement between the parties relating to the subject matter hereof and supersedes any and all prior agreements or understandings written or oral between the parties related to the subject matter hereof. No modification of this Agreement shall be valid unless made in writing and signed by both parties hereto. 17 Governing Law. This Agreement shall be governed by and construed in accordance with the laws of the State of state or province. Exclusive jurisdiction and venue shall be in the county County state or province Superior Court. 17 Binding Effect. This Agreement shall be binding upon and inure to the benefit of Customer and Developers and their respective successors and assigns providing that Developers may not assign any of their obligations under this Agreement without Customers prior written consent. 17 Waiver. The waiver by either party of any Breach or failure to enforce any of the terms and conditions of this Agreement at any time shall not in any way affect limit or waive such partys right thereafter to enforce and compel strict compliance with every term and condition of this Agreement. 17 Good Faith.

Each party represents and warrants to the other that such party has acted in good faith and agrees to continue to so act in the negotiation execution delivery performance and any termination of this Agreement. 17 No Right to Assign. Customer has no right to assign sell modify or otherwise alter the Mobile Software except upon the express written advance approval of Developers whose consent can be withheld for any reason. 17 Right to Interrupt Services Labor or Removal of Mobile Software Resources. In the event Customer fails to make any of the payments set forth on Exhibit within the time prescribed in Exhibit Developers have the right to remove the Mobile Software until payment in full is paid plus accrued late charges of 2% per month. 17 Indemnification.

Developers warrant that the Mobile Software will conform to the Specifications or such other Specifications as are agreed to in writing by Developers for period of thirty days from the date of completion of the Mobile Software. If the Mobile Software does not conform to the Specifications as Customers sole remedy Developers shall be responsible to correct the Mobile Software without unreasonable delay at Developers sole expense and without charge to Customer to bring the Mobile Software into conformance with the Specifications set forth in Exhibit B. This warranty shall be the exclusive warranty available to Customer. Customer waives any other warranty express or implied. Customer acknowledges that Developers are not responsible for the results obtained by Customer on the Mobile Software. Customer acknowledges that Developers are not responsible for fixing problems errors or omissions on the Mobile Software after Customer has tested proofed and approved the Mobile Software and either written approval has been given to Developers or the Mobile Software has been mass produced or transmitted in the Public Domain in any way. Customer waives any claim for damages direct or indirect and agrees that its sole and exclusive remedy for damages either in contract or tort is the return of the consideration paid to Developers as set forth in Exhibit attached hereto. No action regardless of form arising out of any claimed Breach of this Agreement or transactions under this Agreement may be brought by either party more than one year after the cause of action has occurred. 17 No Responsibility for Theft. Developers will have no responsibility for any third party disrupting intruding or otherwise copying files or reverse engineering in part or in whole on all or any part of the Mobile Software at any time. 17. 10 Right to Make Derivative Works. Developers will have the exclusive rights in making any derivative works from any of their work practices coding programming or other work on the Mobile Software that is related to their pre existing Developer Code as outlined in the Specifications. 17. 11 Attorneys Fees. In the event any party to this Agreement employs an attorney to enforce any of the Terms of the Agreement the prevailing party shall be entitled to recover its actual attorneys fees and costs including expert witness fees.

17. 12 Identification of Developers. Customer agrees that Developers identification may be annotated within the code as the authors. Customer also agrees to put Developers copyright notices on the Mobile Software and the relevant content therein. 17. 13 No Responsibility for Loss. Developers are not responsible for any down time lost files lost productivity improper use or any other loss that may occur in the operation of the Mobile Software. 17. 14 Transfer of Rights.

In the event Developers are unable to continue maintenance and support of the Mobile Software non exclusive rights to the Mobile Software will be granted to Customer. This transfer shall not include the transfer of third party Mobile Software or tools used by Developers in the creation or maintenance of the Mobile Software or any part thereof. Each party represents and warrants that on the date first written above they are authorized to enter into this Agreement in entirety and duly bind their respective principals by their signature below. EXECUTED as of the date first written above. company name By signator authorized signature or signer. Job title of signator authorized signature or signer. Date when the contact was signed company name By signator authorized signature or signer.

Job title of signator authorized signature or signer. Date when the contact was signed Customer Initials Developers Initials

A Document from Contract Pack

The editable Project Acceptance Simple Signoff template - complete with the actual formatting and layout is available in the retail Contract Packs.
Proposal Kit on BBB
Proposal Kit
Proposal Kit on FaceBook
Create winning business proposals & contracts with minimal effort and cost. Downloadable proposal software, proposal templates, legal contracts and sample proposals.
© 1997 - 2018, Proposal Kit, Inc. All rights reserved.
Proposal Kit

Create winning business proposals & contracts with minimal effort and cost. Proposal software, proposal templates, legal contracts and sample proposals.