pleased with the multiple number of contracts for different scenarios and I also liked the advice given throughout the different manuals. You turned what would usually be a time-consuming, expensive process into an easy and affordable one that gives professional results."
SOFTWARE INCLUSION AGREEMENT This Licensing Agreement the Agreement is entered into this current day day of current month current year by and between company name state or province company hereafter Licensee and company name hereafter Company This Agreement shall begin on start date and shall terminate on end date unless terminated for any reason by either party upon thirty days prior written notice. Recitals Licensee desires to license Software the Software from Company to be redistributed and included in product released by Licensee the Product or Licensees Product in accordance with the terms of this Agreement and as outlined in Exhibit the Specifications attached herein. Agreements In consideration of the mutual covenants set forth in this Agreement Company and Licensee hereby agree as follows.
5. No Additional Licenses. Company does not grant Licensee the right to use Companys name logo graphics text testimonials quotes or other Company owned material in connection with Licensees Product other than the inclusion of the Software and presentation of this Agreement unless otherwise agreed upon in the Specifications. Licensee acknowledges that Company retains all rights interest and ownership in the Software. At no time will Licensee attempt to derive or be able to assert any title or interest in the Software other than the rights and licenses granted under this Agreement. 6. Reverse Engineering. Licensee may not modify disassemble decompile or otherwise reverse engineer the Software or any component thereof at any time. 7. Termination. Either party may terminate this Agreement at any time for any reason with or without notice. Upon termination of this Agreement all rights granted to Licensee herein shall immediately cease and Licensee must immediately cease distribution of the Software and remove all copies of the Software from circulation where applicable. 8. Risk of Use. Licensee acknowledges that the Software or any component therein may produce unexpected results or errors and may not be suitable for all platforms computers systems or otherwise. Use of the Software by Licensee or any Sublicensee is at their own risk. 9. No Responsibility for Loss.
Company is not responsible for any down time lost files improper links or any other loss that may occur during the installation or use of the Software. 10. Indemnification. Licensee agrees to indemnify and hold Company harmless from any and all claims brought by any third party relating to any aspect of the Software including but without limitation any and all demands liabilities losses costs and claims including attorneys fees arising out of injury caused by Software copyright infringement or Licensees Product. Further Licensee agrees to indemnify Company from responsibility for problems disruptions caused by third party services or tools that Licensee may use such as installation software demos trials delivery systems servers merchant accounts shopping carts shipping hosting services real time credit card processing and other services that relate to the distribution delivery and inclusion of Companys Software in Licensees Product. 11. Export Law. Licensee acknowledges that the Software and its inclusion in Licensees Product are subject to United States export control laws and regulations. Licensee agrees not to export any Software component or other material owned by Company whether directly or indirectly to any country or end user that is subject to United States export restrictions. Licensee shall not import Software into any country except as permitted by the laws and regulations of the applicable country.
12. Communication. Any notice or communication permitted or required by this Agreement shall be deemed effective when personally delivered or deposited postage prepaid by first class regular mail addressed to the other partys last known address. 13. Entire Agreement. This Agreement constitutes the entire Agreement of the parties with regard to the subject matter hereof and replaces and supersedes all other agreements or understanding whether written or oral. No amendment extension or change of the Agreement shall be binding unless it is in writing and signed by all of the parties hereto. 14. Binding Effect. This Agreement shall be binding upon and shall inure to the benefit of Licensee and to Licensees successors and assigns. Nothing in this Agreement shall be construed to permit the assignment by Company of any of its rights or obligations hereunder to any third party without Licensees prior written consent. 15. Disputes.
This Agreement shall be governed by and construed in accordance with the laws of the State of state or province. Exclusive jurisdiction and venue shall be in the county County state or province Superior Court. The prevailing party shall be entitled to recover its reasonable attorney fees and statutory costs. To any portion of this Agreement declared unenforceable that portion shall be construed to give it the maximum effect possible and the remainder of this Agreement shall continue in full force and effect. Each party represents and warrants that on the date first written above they are authorized to enter into this Agreement in entirety and duly bind their respective principals by their signature below. EXECUTED as of the date first written above. company name By signator authorized signature or signer. Job title of signator authorized signature or signer. Date when the contact was signed
company name By signator authorized signature or signer. Job title of signator authorized signature or signer. Date when the contact was signed Company Initials Licensee Initials
EXHIBIT B SPECIFICATIONS The project will contain the following components and or services. A. Describe each deliverable to be included in the project per the terms of the contract and proposal
LICENSING AND ROYALTY AGREEMENT This Licensing Agreement the Agreement is entered into this current day day of current month current year by and between company name state or province company hereafter Licensee and company name hereafter Licensor Recitals 1 The Licensee desires to license content from the Licensor in the following areas of media and design. Insert description of media areas and design. 2 Licensor desires to participate in collaborative collective work and has agreed to provide content and media for the Licensee to be distributed released in collection under the Licensee Name and Brand. Agreements
In consideration of the mutual covenants set forth in this Agreement Licensor and Licensee hereby agree as follows. 1. Licensed Content. Licensor grants to Licensee its agents successors or assigns those for whom Licensee is acting and those acting with its authority and permission the absolute and right and permission to copyright use re use publish and republish recordings copies reproductions digitally sampled and or reconstructed versions of Licensors DVD CD ROM VHS VHS DV Mini DV SWF Fla Digital Artwork and other Media submission in whole or in part including but not limited to any and all animation music video narrative shorts features and trailers in whatever form submitted collectively the Content in any advertising display or product including software releases derivative or ancillary products or works whether such products or works are now in existence or are hereafter created or acquired. Licensor and Licensee further agree that such right and permission has been granted to Licensee on an exclusive basis for use in the Software Graphics Market. Content Description. Insert description of the content to be licensed. 2. Usage. The Content may be copyrighted used and or published individually or in conjunction with other photography video works and recordings and in any medium including without limitation print publications public broadcast CD ROM format and for any lawful purpose including without limitation trade exhibition illustration promotion publicity advertising and electronic publication.
3. Waiver of Approval. Licensor waives any right that Licensor may have to inspect or approve the finished product or products or any advertising copy or printed matter that may be used in connection with such product or the use to which it may be applied. 4. Indemnification. Licensor releases discharges and agrees to hold harmless Licensee its agents successors or assigns and all persons acting under its permission or authority or those for whom it is acting from any liability by virtue of any distortion alteration digitization reconstruction or use in composite form whether intentional or otherwise that may occur or be produced in the recording and subsequent reconstruction of the Content or any other subsequent processing thereof as well as any publication of the resulting materials. 5. Warranties. Licensor warrants that Licensor is of legal age and has every right to contract in Licensors own name in this matter. Licensor further warrants that Licensor has the full right and authority to license the properties to Licensee as provided herein and agrees to indemnify and hold harmless Licensee from any and all expenses suits judgments damages and related costs and fees arising out of Licensors actions omissions negligence or otherwise under this Agreement. Licensor acknowledges that Licensor has read this Agreement prior to its execution and that Licensor is fully familiar with its contents. 6. Compensation. The Licensee will pay Licensor for the following expenses incurred under this Agreement. Insert description of all expenses covered by the Agreement.
7. Independent Contractor. Nothing herein shall be construed to create an employer employee relationship between the parties. The consideration set forth above shall be the sole payment due to Licensor for services rendered. It is understood that the Licensee will not withhold any amounts for payment of taxes from the compensation of Licensor and that Licensor will be solely responsible to pay all applicable taxes from said payment including payments owed to its employees and subagents. 8. Confidentiality. In the course of performing services the parties recognize that Licensor may come in contact with or become familiar with information which the Licensee or its clients may consider confidential. This information may include but not limited to information pertaining to design methods pricing information or work methods of the Licensee as well as information provided by clients of the Licensee for inclusion in Web sites to be developed for clients which may be of value to competitors of the Licensee or its clients. Licensor agrees to keep all such information confidential and not to discuss what evolved any of it to anyone other than appropriate Licensee personnel or their delegates. The parties agree that in the event of breach of this Agreement damages may be difficult to ascertain or prove. The parties therefore agree that if Client breaches this Agreement Licensee shall be entitled to seek relief from court of competent jurisdiction including injunctive relief and shall be entitled to an award of liquidated damages. 9. Term of Agreement.
This Agreement shall begin on start date and shall terminate on end date unless terminated for any reason by either party upon thirty days prior written notice. 10. Communication. Any notice or communication permitted or required by this Agreement shall be deemed effective when personally delivered or deposited postage prepaid by first class regular mail addressed to the other partys last known address. 11. Entire Agreement. This Agreement constitutes the entire Agreement of the parties with regard to the subject matter hereof and replaces and supersedes all other agreements or understanding whether written or oral. No amendment extension or change of the Agreement shall be binding unless it is in writing and signed by all of the parties hereto. 12. Binding Effect. This Agreement shall be binding upon and shall inure to the benefit of Licensee and to the Licensees successors and assigns. Nothing in this Agreement shall be construed to permit the assignment by Licensor of any of its rights or obligations hereunder to any third party without the Licensees prior written consent.
13. Ownership Rights. All plans ideas improvements or inventions developed by Licensor during the term of this Agreement shall belong to the Licensee and or its clients for whom work is being performed as it relates to the Licensees core products and Intellectual Property. Licensor shall however retain the right to display works he creates for Licensee in their portfolio subject to Licensees written approval in advance said approval not to be unreasonably withheld. 14. Governing Law. This Agreement shall be governed by and construed in accordance with the laws of the State of state or province. Exclusive jurisdiction and venue shall be in the county County state or province Superior Court. The prevailing party shall be entitled to recover its reasonable attorney fees and statutory costs. To any portion of this Agreement declared unenforceable that portion shall be construed to give it the maximum effect possible and the remainder of this Agreement shall continue in full force and effect. Each party represents and warrants that on the date first written above they are authorized to enter into this Agreement in entirety and duly bind their respective principals by their signature below. EXECUTED as of the date first written above. company name By signator authorized signature or signer. Job title of signator authorized signature or signer.
Date when the contact was signed company name By signator authorized signature or signer. Job title of signator authorized signature or signer. Date when the contact was signed Licensee Initials Licensor Initials
DATABASE APPLICATION DEVELOPMENT AGREEMENT THIS AGREEMENT is made this current day day of current month current year by and between company name Developers and company name Customer Recitals A. Developers have experience and expertise in the development of Database Applications and Software Database Product B. Customer desires to have Developers develop Database Product for them. C. Developers desire to develop Customers Software on the terms and conditions set forth in Exhibit attached hereto the Specifications Definitions Database shall mean collection of any form of data including clear or encrypted text images sound video or multimedia. Relational Database shall mean database that maintains set of separate related files tables but combines data elements from the files for queries and reports as requested. For the purpose of this agreement it shall also include the finite set of relation schemas and corresponding set of relation instances database instance that represents data as two dimensional tables and contains the following components. set of domains and set of relations operations on relations and data integrity rules to ensure Database Integrity.
Primary Key shall mean field column in database table that uniquely identifies each record in the table that is indexed and maintains the main sequence of the table. Foreign Key shall mean field in relational table in database that is indexed in another table and matches the primary key column of another table. Database Integrity shall mean the correctness and consistency of the data stored in the Database or any aspect of the Database Product. Relational Data Model RDM shall mean description of the organization of database that allows for it to be modeled and all attributes and tables including all fields and records to be graphically represented. Database Schema shall mean set of relation schemas for the relations in the design and development of the Database Product. Relation Schema shall mean the names of relations that must be unique across the database. Integrity Constraints shall mean restrictions on the relational instances of schema. Schema shall mean definition for database. Deliverables shall mean the Database Product provided in object and or source format as set forth in the Specifications and subject to Developers Proprietary Rights documentation or other materials required to be delivered by Developers to Customer as set forth in the Specifications.
Critical Deliverables shall mean Deliverables that have Milestone date as outlined in the Specifications that must be transmitted to Customer on or before specific date. Source Code shall mean the readable forms together with make and build files. Beta shall mean any and all Deliverables provided to Customer prior to the Launch Date. Final shall mean any and all Deliverables provided to Customer that are in accordance with the Specifications and accepted by Customer as completion of particular Deliverable. Launch Date shall mean the date that the Product is first available for use by the public.
Software shall mean the Database Applications program described in the Specifications that is are to be developed by Developers including all Enhancements made under this Agreement. Product shall mean software for computer or an end user. Schedule shall mean the schedule for completion of the Deliverables as set forth in the Specifications. Delivery shall mean transmitted by Developers to Customer electronically and in accordance with security measures agreed upon by both parties in accordance with the Specifications. Services shall mean any training customization enhancement or other labor performed by Developers as required by the Specifications. Error shall mean malfunctions or defect within the Database Product or Deliverable that prevents it from conforming to the Specifications. Internet shall mean any system for distributing digital or electronic information to end users via transmission broadcast or any other form of delivery whether direct or indirect known or subsequently developed.
Specifications shall mean the specifications for the Product and Services as detailed and attached to this Agreement as Exhibit which include detailed specifications and instructions for all required Deliverables features and functionality and complete production schedule for each Deliverable and Milestone. Term shall mean the period of time commencing on the Effective Date of this Agreement and continuing indefinitely until this Agreement is terminated. User Interface shall mean all navigational devices menus menu structures or arrangements icons visual mechanisms metaphors or help and other operational instructions and all other components of any source or object computer code that comprises the Database Product. Web shall mean the World Wide Web containing pages written in hypertext markup language HTML and or any similar successor technology. Web Page shall mean any document that may be viewed in its entirety on the Web. Web Site shall mean collection of interrelated Web pages or documents accessible through Web page browser interface or any other similar successor technology. Developers Proprietary Material shall mean all intellectual property rights in any text images or other components and or materials owned by Developers or which Developers have the legal right to use that are delivered to Customer including but not limited to software related documentation source code scripts object code logos graphics or tag lines. Customers Proprietary Material shall mean all intellectual property rights in any text images or other components and or materials owned by Customer or which Customer has the legal right to use that are delivered to Developers including but not limited to software related documentation Customer marketing material logos graphics or tag lines. Developers Code shall mean all Developers Proprietary Material or software Source Code existing as of the date of this Agreement that is to be incorporated into the Source Code of the Product. The license terms for Developers Code will be stated in the Specifications.
Documentation shall mean all user guides reference integration installation or implementation manuals that describe in detail the operation of the Software that is normally provided by Developers as part of their deliveries to their customers. Development Activities shall mean any activities undertaken by Developers in the development of the Software and Documentation satisfying the Specifications pursuant to this Agreement. Enhancements shall mean error corrections bug fixes modifications and updates not included in the Specifications with respect to the Software. Milestone shall mean each development or Deliverable reached by Developers and agreed upon in writing between Developers and Customer. Milestone Payment shall mean payment obligation related to the achievement and acceptance of particular Milestone. Acceptance shall mean completion of Deliverable that conforms to the Specifications and is mutually agreed upon in writing by both Developers and Customer. Agreements In consideration of the mutual covenants set forth in this Agreement Customer and Developers hereby agree as follows. 1. Development of Database Product.
Developers agree to installation management documentation and development of the Software and Software based operations according to the compensation terms listed on Exhibit attached hereto. 2. Specifications. Developers agree to develop the Software pursuant to the Specifications set forth in Exhibit attached hereto the Specifications 3. Delivery Dates and Milestones. Developers will use reasonable diligence in the development of the Database Product and endeavor to deliver to Customer operational Software no later than delivery date. Customer acknowledges however that this delivery deadline and the other payment milestones listed in Exhibit are estimates and are not required delivery dates unless otherwise noted in the Specifications. Deliverables defined as Critical Deliverables shall be outlined in Exhibit and shall contain the delivery date and terms of delivery of the Critical Deliverable. Developers will be retaining the Source Code for the Database Product and providing Customer with the output formats only. The output is to be used only within the scope of the Software as outlined in Exhibit and does not include the following. replication duplication or otherwise copying the Software in any form not authorized by Developers creating new Software based on the code its functions or other Proprietary Rights as outlined in Paragraph sale or distribution of the code in any form or any relinquishment of copyright by Developers in any way. 4. Ownership Rights. Except for Customers Proprietary Material defined below contained in the Database Product Developers shall hold all rights title and interest in and to the Software. Specifically but without limitation Developers shall hold all rights title and interest in and to all text graphics animation audio components and digital components of the Software the Content all interfaces navigational devices menus menu structures or arrangements icons help and other operational instructions and all other components of any source or object computer code that comprises the Software all literal and nonliteral expressions of ideas that operate cause create direct manipulate access or otherwise affect the Content and all copyrights patents trade secrets and other intellectual or industrial property rights in the Software or any component or characteristic thereof. Customer shall not do anything that may infringe upon or in any way undermine Developers rights title and interest in the Software as described in this Paragraph 4. Notwithstanding the above Customer shall retain and Developers shall have no Proprietary Rights whatsoever in all of Customers intellectual property rights in any and all text images or other components and or materials owned by Customer or which Customer has the legal right to use that are delivered to Developers including but not limited to software related documentation Customer marketing material logos and tag lines Customers Proprietary Material Developers agree that they shall not use Customers Proprietary Material for any other purpose than those expressly set forth in this Agreement. 5. Database Product Development and Construction Rules. Database Product Development and Services described here are provided for Linux Windows Macintosh Sun Solaris UNIX systems only unless otherwise specified.
Unless otherwise agreed upon by Developers and Customer any modifications required to the Software code or other component related to its operation that are result of third party changes to resources required by the Software shall be considered ADDITIONAL and will fall outside of the Specifications. Third party modifications may include but are not limited to. patches fixes security flaws errors updates upgrades or any other changes to third party operating systems plug ins or any required resources not created by Developers. Unless otherwise defined in the Specifications the Database Product will be developed in accordance with the following RDM standards. 5 Database Integrity. The data held in the tables shall be consistent with the Relational Data Model RDM and shall incorporate. * Entity Integrity. Each row in the table representing single instance of the entity type modeled by the table will have Unique and Non null primary key value. Each column in the table representing single instance of the entity type modeled by the table shall have entries of the appropriate data type. * Referential Integrity. Data held in single table or tables shall not contradict data held elsewhere in another table. Developers will ensure that every Foreign Key value in table must have matching Primary Key value in the corresponding table. * Data Validation. Developers will employ additional features to ensure data integrity upon inserting of data creating new rows or any other aspect that interacts with the Database Product.
6. Specific Enhancements. Developers and Customer acknowledge that at some time during the Term of this Agreement that enhancements to the Database Product may be proposed by either Developers or Customer which fall outside of the scope of the Specifications. Upon such proposal Developers shall confer in good faith with Customer concerning the feasibility of developing such enhancements and the time frame for developing testing and incorporating such enhancements. Developers and Customer shall mutually agree in writing as to whether Developers shall pursue the development of such enhancements and if so which party will fund such development. The Specifications will be amended to include such enhancements. 7. Backups and Redundancies for Development. Developers will maintain off site storage of all stages of the Source Code and other backup media related to this Agreement to ensure Software integrity and protection and will be responsible for setting up daily procedure for backing up all data. Developers agree to update all backups of code on daily basis unless otherwise agreed upon in the Specifications. Backups will be maintained for one year from the acceptance date of the project. 8. Acceptance. The terms and conditions contained in this Section will apply to the initial release of the Database Product as well as to subsequent release upgrades enhancements or any other version thereof. Customer shall evaluate any beta or final version of each Deliverable and shall submit an acceptance or rejection to Developers within days days after Customers receipt of an agreed upon transmission of each Deliverable. 9. Testing and Quality Assurance.
Developers agree to thoroughly test the Database Product including without limitation each and every release version and enhancement thereof as appropriate under the circumstances at all appropriate stages of development and shall document its testing by written test documents delivered to Customer. Developers will submit their test plans to Customer so as to ensure that Customers standards of quality are maintained and Developers agree to subsequently modify the test plans to accommodate Customers requests if Customer reasonably deems necessary. Quality Assurance or test documentation shall include detailed descriptions of the tests conducted their results and any outstanding or unresolved issues. Developers will not deploy the Product Software or any enhancement thereof unless Customer and Developers agree upon such action in writing. 9 Database Integrity. Developers agree to build in safeguards to ensure Database Integrity and to make sure that relationships between tables remain consistent. Safeguards may include but are not limited to. Iterative and incremental backups and restore points comparisons between Primary and Foreign Keys use of referential integrity to ensure that records are not improperly added to table that contains the Foreign Key ensuring exceptions for corresponding records in linked tables adding cascading updates and cascading deletes to ensure changes made to the linked tables are reflected in the primary table and any other requirement contain in the Specification concerning Database Integrity. 10. Adherence to Schedule. If Developers fail transmission of any Critical Deliverable within the dates specified in the Schedule or fail to meet Milestone as defined in the Specifications then Breach of Agreement Breach shall be considered to have occurred. Customer may. amend the Schedule to include correction period; or suspend the Schedule until the problem is corrected at the sole expense of Developers subject to Customers reasonable satisfaction; or terminate this Agreement. Delivery of all Deliverables not defined in the Specifications as Critical Deliverables shall be considered estimates and delivery shall not be subject to Breach. Developers shall not be held responsible for any delays due to. milestones missed by Customer delays due to Customer Deliverables delays due to transmission equipment failure strikes riots disasters or other natural occurrences.
11. Support Services. Developers will be available to respond to Customers questions about the Database Product and related problems. Developers will staff help desk with combination of phone and email support services from 9. am to 5. pm Monday through Friday time zone. Developers will be responsible for maintaining an ongoing log of support requests and actions taken and for tracking user support requests to completion for the duration of this Agreement. 12. Compensation. For all of Developers Services under this Agreement Customer shall compensate Developers in cash pursuant to the terms of Exhibit attached hereto. In the event Customer fails to make any of the payments referenced in Exhibit by the deadline set forth in Exhibit Developers have the right but are not obligated to pursue any or all of the following remedies. terminate the Agreement remove equipment owned by Developers whether leased to Customer by Developers or not and any Developers Personnel or Staff from Customers location bring legal action or Customer may suspend development of the Database Product and is responsible for any schedule changes required and additional financial impact. 13. Confidentiality.
Customer and Developers acknowledge and agree that the Specifications and all other documents and information related to the development of the Database Product including the information contained within the database regardless if that data is fictional or not the Confidential Information will constitute valuable trade secrets of the Customer. Developers shall keep the Confidential Information in confidence and shall not at any time during or after the term of this Agreement without Customers prior written consent disclose or otherwise make available to anyone either directly or indirectly all or any part of the Confidential Information. 14. Limited Warranty and Limitation on Damages. Developers warrant that the Database Product will conform to the Specifications. If the Software does not conform to the Specifications Developers shall be responsible to correct the Software without unreasonable delay at Developers sole expense and without charge to Customer to bring the Database Product into conformance with the Specifications. This warranty shall be the exclusive warranty available to Customer. Customer waives any other warranty express or implied. Customer acknowledges that Developers do not warrant that the Software will work on all platforms. Customer acknowledges that Developers will not be responsible for the results productivity or any other measurable metric not specified in Exhibit obtained by Customer on the Software. Customer waives any claim for damages direct or indirect and agrees that its sole and exclusive remedy for damages either in contract or tort is the return of the consideration paid to Developers as set forth in Exhibit attached hereto. Developers will monitor the reliability and stability of the Database Product for period of up to thirty days to ensure that it performs in accordance with the Specifications. If modifications are required at any time Developers will confer in good faith with Customer concerning the appropriateness of any modifications and mutually agree whether or not to make such modifications; provided however that such agreement will not be deemed to relieve Developers from their obligations to ensure that the Product continues to conform to the Specifications and compensation estimates as specified in Exhibit A. 15. Independent Contractor.
Developers shall be retained as independent contractors. Developers will be fully responsible for payment of their own income taxes on all compensation earned under this Agreement. Customer will not withhold or pay any income tax social security tax or any other payroll taxes on Developers behalf. Developers understand that they will not be entitled to any fringe benefits that Customer provides for its employees generally or to any statutory employment benefits including without limitation workers compensation or unemployment insurance. 16. Equipment. Customer agrees to make available to Developers for Developers use in performing the services required by this Agreement such items of hardware and software as Customer and Developers may agree are reasonably necessary for such purpose. 17. General Provisions. 17 Entire Agreement. This Agreement contains the entire agreement between the parties relating to the subject matter hereof and supersedes any and all prior agreements or understandings written or oral between the parties related to the subject matter hereof. No modification of this Agreement shall be valid unless made in writing and signed by both parties hereto. 17 Governing Law. This Agreement shall be governed by and construed in accordance with the laws of the State of state or province. Exclusive jurisdiction and venue shall be in the county County state or province Superior Court.
17 Binding Effect. This Agreement shall be binding upon and inure to the benefit of Customer and Developers and their respective successors and assigns providing that Developers may not assign any of their obligations under this Agreement without Customers prior written consent. 17 Waiver. The waiver by either party of any Breach or failure to enforce any of the terms and conditions of this Agreement at any time shall not in any way affect limit or waive such partys right thereafter to enforce and compel strict compliance with every term and condition of this Agreement. 17 Good Faith. Each party represents and warrants to the other that such party has acted in good faith and agrees to continue to so act in the negotiation execution delivery performance and any termination of this Agreement.
17 No Right to Assign. Customer has no right to assign sell modify or otherwise alter the Software except upon the express written advance approval of Developers whose consent can be withheld for any reason. 17 Right to Interrupt Services Labor or Removal of Software Resources. In the event Customer fails to make any of the payments set forth on Exhibit within the time prescribed in Exhibit Developers have the right to remove the Software until payment in full is paid plus accrued late charges of 2% per month. 17 Indemnification. Developers warrant that the Software will conform to the Specifications or such other Specifications as are agreed to in writing by Developers for period of thirty days from the date of completion of the Software. If the Software does not conform to the Specifications as Customers sole remedy Developers shall be responsible to correct the Software without unreasonable delay at Developers sole expense and without charge to Customer to bring the Software into conformance with the Specifications set forth in Exhibit B. This warranty shall be the exclusive warranty available to Customer. Customer waives any other warranty express or implied. Customer acknowledges that Developers are not responsible for the results obtained by Customer on the Software. Customer acknowledges that Developers are not responsible for fixing problems errors or omissions on the Software after Customer has tested proofed and approved the Software and either written approval has been given to Developers or the Software has been mass produced or transmitted in the Public Domain in any way. Customer waives any claim for damages direct or indirect and agrees that its sole and exclusive remedy for damages either in contract or tort is the return of the consideration paid to Developers as set forth in Exhibit attached hereto. No action regardless of form arising out of any claimed Breach of this Agreement or transactions under this Agreement may be brought by either party more than one year after the cause of action has occurred. 17 No Responsibility for Theft. Developers will have no responsibility for any third party disrupting intruding or otherwise copying files or reverse engineering in part or in whole all or any part of the Software at any time.
17. 10 Right to Make Derivative Works. Developers will have the exclusive rights in making any derivative works from any of their work practices coding programming or other work on the Software that is related to their pre existing Developers Code as outlined in the Specifications. 17. 11 Attorneys Fees. In the event any party to this Agreement employs an attorney to enforce any of the Terms of the Agreement the prevailing party shall be entitled to recover its actual attorneys fees and costs including expert witness fees. 17. 12 Identification of Developers. Customer agrees that Developers identification may be annotated within the code as the authors. Customer also agrees to put Developers copyright notices on the Software and the relevant content therein. 17. 13 No Responsibility for Loss. Developers are not responsible for any down time lost files lost productivity improper use or any other loss that may occur in the operation of the Software.
17. 14 Transfer of Rights. In the event Developers are unable to continue maintenance and support of the Software non exclusive rights to the Software will be granted to Customer. This transfer shall not include the transfer of third party Software or tools used by Developers in the creation or maintenance of the Software or any part thereof. The parties represent and warrant that on the date first written above they are authorized to enter into this Agreement in its entirety and duly bind their respective principals by their signatures below. EXECUTED as of the date first written above. company name By signator authorized signature or signer. Job title of signator authorized signature or signer. Date when the contact was signed company name
By signator authorized signature or signer. Job title of signator authorized signature or signer. Date when the contact was signed Customer Initials Developers Initials