This contract document is also included in the discounted Proposal Kit Professional bundle. Order and download for $199.
The Social Networking Services agreement is a specialized version of the software and web site contracts. This version is used when you are going to develop and deploy social networking strategies, a custom social networking site, design a social networking campaign, provide custom programming and integration services.
Document Length: 8 Pages
Business proposal example Contract Pack

Professional has helped me from the beginning. It doesn’t matter whether we have a client that is a family friend or a brand new client; we always send them a contract. It is so important to act professional from the beginning."

Laura Fedock
Elle-Design
The actual document is delivered in the retail products as an editable template.
Produced by:
Proposal Kit
Category:
Software > Computer Software > Business & Productivity Software
Price:
$199 USD
 
 
Proposal Kit reviews4.9 stars, based on over 700 reviews
Alternate documents are those which may be used instead of this document depending on your situation. Alternate documents may be better suited for different size projects, more specialized projects, variations on rights, etc.

Alternate Documents:
Related documents may be used in conjunction with this document depending on your situation. Many related documents are intended for use as part of a contract management system.

Related Documents:
Social Networking Services Contract
Disclaimers: Proposal Kit, Inc. makes no warranty and accepts no responsibility for suitability of any materials to licensees business. Proposal Kit, Inc. assumes no responsibility or liability for errors or inaccuracies. Licensee accepts all responsibility for results obtained. Information included is not legal advice. Use of any supplied materials constitutes acceptance and understanding of these disclaimers.

How do you write a Social Networking Services Contract document?

SOCIAL NETWORKING SERVICES AGREEMENT THIS AGREEMENT is made this current day day of current month current year by and between company name Company and company name Customer Recitals A. Company has experience and expertise in the development of social networking social networking platform strategies for web pages web sites and other computer networks. B. Customer desires to have Company develop and deploy social networking strategies and custom social networking site design social networking campaign provide custom programming and integration services and other services as outlined in Exhibit attached herein the Specifications C. Company desires to develop Customers social networking strategy and services on the terms and conditions set forth herein.

Agreements In consideration of the mutual covenants set forth in this Agreement Customer and Company hereby agree as follows. 1. Development of Social Networking Strategy and Optimization Services. Company agrees to create install edit manage develop and employ custom social networking strategies according to the terms listed on Exhibit attached hereto. 2. Specifications. Company agrees to develop the social networking pursuant to the Specifications set forth in Exhibit B. 3. Delivery Dates and Milestones.

Company will use reasonable diligence in the development of the social networking services and endeavor to deliver to Customer all deliverables and milestones no later than delivery date. Customer acknowledges however that this delivery deadline and the other payment milestones listed in Exhibit are estimates and are not required delivery dates. Company will retain all documents source code password lists and other assets employed or created for Customer during the execution of this agreement. Customer will only receive the output formats of Companys work where applicable. The output is to be used only within the scope of the project as outlined in Exhibit A. Customer shall retain all of its intellectual property rights in any text images or other components it owns and delivers to Company for use in the social networking services rendered under this agreement. 4. Services Provided. Social networking services are intended to establish for the Customer presence across multiple social networking platforms as outlined in Exhibit B. Services may include specific campaigns to drive traffic to or build membership in various social networking platforms as well as reporting results on an ongoing and timely basis. Social networking services may include but are not limited to the following. 4 Social Networking Site Selection. Company will provide comprehensive list of social networking sites and platforms based upon research completed by Company and presented to Customer that best suits the demographic Customer is trying to reach with its social networking efforts.

4 Social Networking Site Page or Account Creation Edits and Custom Programming. Company will create or edit Customers existing social networking site page or account as deemed necessary by Company in order to meet the goals as stated in the Specifications. Company will register Insert the social networking domain count additional domains to be used as gateways to improve social networking services. Registration shall be in Customers name and schedule of fees for maintaining the additional domains shall be billed to Customer accordingly. Company will create Insert additional campaigns additional campaigns for the purpose of targeting specific agreed upon demographics in order to drive interest in Customers social networking efforts. These campaigns will be placed in locations determined to be most effective and at Companys sole discretion. Company may employ proprietary techniques coding and other resources as it deems necessary to improve Customers social networking efforts. Company reserves the right to create specially coded Web Pages to prevent competitors from copying code or any resources employed by Company. 4 Software. Company will install update upgrade and configure the following software packages the Installation or the Software as required by the Specifications and provide documentation and instructions to Customer on using all Software installed by Company. Company shall provide hours hours of training to Customer and turn over all disks CD ROMs digital media downloads links or other Software purchased for Customer under this Agreement to Customer. Company shall not be responsible for keeping copies back ups or any other form of the Software after turning over the original copies to Customer. Company will not maintain the Installation updates or any daily tasks required for the maintenance of the Software under this Agreement unless otherwise specified in Exhibit B. Company will not manage or maintain copies of licenses for any of the software packages or installations under this Agreement. All licenses for software installations will be turned over to Customer upon execution of this Agreement. 4 Social Networking and Management Services.

Company will manage Customers social networking accounts and pages as stated in the Specifications. Insert services related to specific social networking accounts and other disclaimers if used. Company will create custom reports for social networking efforts and positioning of Customers social networking Site or other custom Pages created by Company under this Agreement. Company will provide detailed reports as required by the Specifications and shall endeavor to provide the reports to Customer in timely manner. Customer acknowledges that any reports provided by Company are to be considered estimates based on industry standard reporting software and techniques and shall never be construed as an exact counting of each and every submission. Insert exclusions to reporting and other disclaimers if any. Company will provide editing services and continue to adjust all Accounts Pages Fan Sites Business Sites and other media created under this Agreement for period of days days in order to increase the effectiveness of social networking services. Insert exclusions to editing services and other disclaimers if any.

Company will create and employ the following third party tools for Customer. Insert specifics including number of keywords pay per click campaign maximum bids etc. Insert additional services to be performed for Customer under this Agreement if any. Company will develop and maintain regular monitoring and reporting on social networking and Third Party Advertising Performance that is used in conjunction with the social networking Services. Reports will be provided to Customer on monthly basis. Customer acknowledges the following with respect to services. a Company accepts no responsibility for policies of third party social networking Sites Directories or other Web Sites Third Party Resources that Company may use with respect to the classification or type of content it accepts whether now or in the future. Customers social networking Sites Web Site or content may be excluded or banned from any Third Party Resource at any time. Customer agrees not to hold Company responsible for any liability or actions taken by Third Party Resources under this Agreement. b Customer acknowledges that the nature of many of the resources Company may employ under this Agreement are competitive in nature. Company does not guarantee #1 positions consistent positioning top positions or guaranteed placement for any particular social networking Site Keyword Phrase or Search Term s. Customer acknowledges that Companys past performance is not indicative of any future results Customer may experience. c Customer acknowledges that social networking and submissions can take an indefinite amount of time for results and inclusion unless paid advertising programs are employed. Each edit or change made to any resources employed by Company will repeat these times. d Customer acknowledges that any of the social networking sites or other resources may block prevent or otherwise stop accepting information for an indefinite period of time.

e Customer acknowledges that any search engine may drop social networking sites from its database for no apparent or predictable reason. Company shall adhere to the current policies of the social networking site in question and whether pay inclusion programs are being used. f Company will endeavor to make every effort to keep Customer informed of any changes that Company is made aware of that impact any of the social networking services and the execution thereof under this Agreement. Customer acknowledges that Company may not become aware of changes to Third Party Resources industry changes or any other changes that may or may not affect social networking services. g Customer acknowledges that some of the Third Party Resources offer only paid inclusion programs that require fee or continued maintenance or performance fees. Customer is solely responsible for all paid advertising fees and must maintain adequate funds in any third party accounts in order to maintain inclusion in these resources. Consult Exhibit for complete list of Third Party Resources employed under this Agreement and an estimate of fees for specific advertising keyword targets and other listings. h Company reserves the exclusive right for the duration of this Agreement to approve or disapprove any design strategies existing code or other techniques whether requested by Customer or presently employed by Customer that are considered by Company to be detrimental to social networking and the execution of Companys services under this Agreement. 5. Compensation.

For all of Companys services under this Agreement Customer shall compensate Company in cash pursuant to the terms of Exhibit attached hereto. In the event Customer fails to make any of the payments referenced in Exhibit by the deadline set forth in Exhibit Company has the right but is not obligated to pursue any or all of the following remedies. terminate the Agreement remove equipment software services or resources owned by Company whether leased to Customer by Company or not and any Company personnel or staff from Customer location bring legal action. 6. Confidentiality. Customer and Company acknowledge and agree that the Specifications and all other documents and information related to the development of social networking the Confidential Information will constitute valuable trade secrets of Company. Customer shall keep the Confidential Information in confidence and shall not at any time during or after the term of this Agreement without Companys prior written consent disclose or otherwise make available to anyone either directly or indirectly all or any part of the Confidential Information. 7. Limited Warranty and Limitation on Damages. Company warrants that social networking products and services will conform to the Specifications for period of days from the date of acceptance by Customer. If social networking services do not conform to the Specifications Company shall be responsible to correct social networking services without unreasonable delay at Companys sole expense and without charge to Customer to bring social networking services into conformance with the Specifications. This warranty shall be the exclusive warranty available to Customer. Customer waives any other warranty express or implied. Customer acknowledges that Company does not warrant that social networking services will work on all platforms. Customer acknowledges that Company will not be responsible for the results press reputation productivity or any other measurable metric not specified in Exhibit obtained by Customer on social networking services. Customer waives any claim for damages direct or indirect and agrees that its sole and exclusive remedy for damages either in contract or tort is the return of the consideration paid to Company as set forth in Exhibit attached hereto. Developers note. When creating the Specifications in Exhibit make sure to clearly outline the services to be performed which you have control over. It is not recommended to include expected results in Specifications as you may not be able to then meet the terms of your Agreement and maintain results for the entire warranty period. If you do agree to terms you may not have control over in the Specifications consider removing the default 30 day warranty and specify there is no warranty. You want to ensure to always agree only to Specifications you can complete. For example do not warrant that social networking sites will list any campaign in the top results on search but do warrant that you performed all content creation and distribution of content per the guidelines of the specified social networking platforms. 8. Independent Contractor.

Writing the Exhibit F (Project Change Form) document (alternate or related contract document)

EXHIBIT F CONTRACT ADDENDUM THIS AGREEMENT is made this current day day of current month current year by and between company name Company and company name Customer The following requirements are made and are to be included as part of the attached contract.

ADDENDUM A. Project Change Request Insert Addendum A. Information Here ADDENDUM B. Financial Impact and Schedule Impact Insert Addendum B. Information Here Each party represents and warrants that on the date first written above they are authorized to enter into this Agreement in entirety and duly bind their respective principals by their signature below. EXECUTED as of the date first written above. company name

By signator authorized signature or signer. Job title of signator authorized signature or signer. Date when the contact was signed company name By signator authorized signature or signer. Job title of signator authorized signature or signer. Date when the contact was signed

Customer Initials Company Initials

How to write my Email Marketing and Campaign Agreement document (alternate or related contract document)

EMAIL MARKETING AND CAMPAIGN MANAGEMENT AGREEMENT THIS AGREEMENT is made this current day day of current month current year by and between company name Agency and company name Customer Recitals A. Agency is in the business of providing email marketing and email campaign management services for fee. B. Customer desires to have Agency render certain email marketing and campaign management services the Services as set forth in Exhibit B. C. Agency desires to render email marketing and campaign management services as set forth in Exhibit B.

Agreements In consideration of the mutual covenants set forth in this Agreement Customer and Agency hereby agree as follows. 1. Engagement of Services. Agency agrees to render to Customer services in connection with the planning preparing and creation of an Email Marketing Campaign including. a Create design mockups and comps for all creative materials or content to be used with Customer approval in Email Marketing Campaigns.

b Create different types of content templates such as HTML Flash Rich Media Text AOL Text or Lotus Notes specific content templates. c Develop advertising ideas and creative content for Customer for approval for use in email marketing programs. d Prepare estimates of costs and expenses associated with idea and content development and present them to Customer for approval. e Design contract or otherwise arrange for the preparation or programming of response tracking open rates click through rates bounce handling blocked email tracking black and white list handling ROI tracking response devices alternate content delivery auto responders opt out forward to friend campaign management tools analytic tools predictive modeling or any other related service or device that the Customer may request. f Provide proofing and editing services on behalf of Customer to check for accuracy completeness adherence to specifications and Customer branding in all forms of contracted advertising that Agency handles on behalf of Customer.

g Audit all invoices and expenses provided by third party vendors to ensure accuracy. h Provide other services as Customer may request from time to time such as content creation assistance to Customers staff and employees market research analysis or additional project consulting. i Execute all other advertising and marketing services or campaign management as agreed upon in Exhibit B. 2. Specifications. Agency agrees to develop the advertising and consulting services pursuant to the specifications set forth in Exhibit attached hereto the Specifications 3. Services Completion. Agency will use reasonable diligence in the development of the Email Marketing Campaign Services and endeavor to deliver to Customer all agreed upon specifications or Milestones outlined in Exhibit no later than delivery date. Customer acknowledges however that this delivery deadline and the other payment milestones listed in Exhibit are estimates and are not required delivery dates. Agency will retain all creative source code original works files digital media and other intellectual property for the entire project and provide Customer with the output formats only. Customer shall retain all of its intellectual property rights in any logos graphics text images or other components it owns and transmits to Agency for use in fulfillment or creation of services. 4. Ownership Rights.

a Agency shall endeavor to ensure that Customer shall be able to retain under the fullest extent under the law any and all intellectual property rights in any text images or other components created for Customer pursuant to this Agreement. b Customer agrees that any material content plan or idea prepared by Agency or submitted to Customer for approval at any stage that is not utilized at the termination of this Agreement shall remain the property of Agency. Customer agrees to return to Agency any materials it may have of Agencys such as artwork mock ups comps text digital media film photos or any other physical embodiment of Agencys creative work performed while under this Agreement. c Upon termination or expiration of this Agreement Customer agrees to be solely responsible for any additional use of materials and advertisements created by Agency pursuant to this Agreement. Additional expenses may include but are not limited to. fees licenses translations royalties talent and other associated fees. Agencys obligation in 4. shall not apply with any respect to foreign use. 5. Compensation. For all of Agencys services under this Agreement Customer shall compensate Agency in cash pursuant to the terms of Exhibit attached hereto. In the event Customer fails to make any payment referenced in Exhibit by the deadline set forth in Exhibit Agency has the right but is not obligated to pursue any or all of the following remedies. terminate the Agreement withhold all materials services and creative content administered by Agency on behalf of Customer or bring legal action. 6. Confidentiality. Customer and Agency acknowledge and agree that the Specifications and all other documents and information related to the engagement of marketing or advertisement development the Confidential Information will constitute valuable trade secrets of Agency. Customer shall keep the Confidential Information in confidence and shall not at any time during or after the term of this Agreement without Agencys prior written consent disclose or otherwise make available to anyone either directly or indirectly all or any part of the Confidential Information. Excluded from the Confidential Information definition is anything that can be seen by the public in any advertising medium or channel prior to the engagement of Agency to provide services or information that was provided to Agency by Customer for publication as requirement of fulfillment of the Specifications. 7. Limited Warranty and Limitation on Damages. Customer agrees to indemnify and hold Agency harmless with respect to any claim loss lawsuit liability or judgment suffered by Customer that results from the use of any material prepared or execution of service by Agency or at the direction of Agency that has been materially changed from the Specifications by any advertisers publishers hosts radio and television broadcasts quotes testimonials print journalism or other third party entity.

Agency agrees to obtain and or maintain in force for the length of this Agreement at Agencys expense an appropriate liability policy or policies having minimum limit of amount insurance coverage naming Customer as an additional insured and loss payee under such policy or policies as applicable. In the event of any litigation proceeding or suit against Customer by any regulatory agency or in the event of court action challenging any advertising or marketing service prepared by Agency Agency shall assist in the preparation of defense of such action and cooperate with Advertiser. Customer acknowledges that Agency is not responsible for the results obtained by Customer from any creative services advertising programs ideas or execution thereof. Customer waives any claim for damages direct or indirect and agrees that its sole and exclusive remedy for damages either in contract or tort is the return of the consideration paid to Agency as set forth in Exhibit attached hereto. 7 Right of Refusal. Agency reserves the right to refuse any service or services at any time that appear to be in violation with its Acceptable Use Policy AUP or appears to be in violation with industry standards community standards or violation of Local State or Federal Law. Agency will make available to Customer its AUP prior to the engagement of this Agreement. Agency reserves the sole right to determine what constitutes violation of its policies and procedures. 7 No Warranty on Campaign Success or Results. Agency is not responsible for the results obtained from any of the services rendered under this Agreement. 7 Compliance with the CAN SPAM Act of 2003.

Agency and Customer and all email campaigns or related communicates sent on behalf of the customer by the Agency or the Agencys agents or vendors must comply with the CAN SPAM Act of Controlling the Assault of Non Solicited Pornography and Marketing Act which establishes requirements for those who send commercial email. 8. Independent Contractor. Agency will be retained as independent contractor. Agency will be fully responsible for payment of its own income taxes on all compensation earned under this Agreement. Customer will not withhold or pay any income tax social security tax or any other payroll taxes on Agencys behalf. Agency understands that it will not be entitled to any fringe benefits that Customer provides for its employees generally or to any statutory employment benefits including without limitation workers compensation or unemployment insurance. 9. Resources and Equipment. Customer agrees to make available to Agency for Agencys use in performing the services required by this Agreement all logos graphics photos branding collateral items of hardware and software as Customer and Agency may agree are reasonably necessary for such purpose. 10. General Provisions. 10 Entire Agreement. This Agreement contains the entire agreement between the parties relating to the subject matter hereof and supersedes any and all prior agreements or understandings written or oral between the parties related to the subject matter hereof. No modification of this Agreement shall be valid unless made in writing and signed by both of the parties hereto. 10 Governing Law.

This Agreement shall be governed by and construed in accordance with the laws of the State of state or province. Exclusive jurisdiction and venue shall be in the county County state or province Superior Court. 10 Binding Effect. This Agreement shall be binding upon and inure to the benefit of Customer and Agency and their respective successors and assigns provided that Agency may not assign any of its obligations under this Agreement without Customers prior written consent. 10 Waiver. The waiver by either party of any breach or failure to enforce any of the terms and conditions of this Agreement at any time shall not in any way affect limit or waive such partys right thereafter to enforce and compel strict compliance with every term and condition of this Agreement. 10 Good Faith. Each party represents and warrants to the other that such party has acted in good faith and agrees to continue to so act in the negotiation execution delivery performance and any termination of this Agreement.

10 Right to Withhold Content and Services. In the event Customer fails to make any of the payments set forth on Exhibit within the time prescribed in Exhibit Agency has the right to withhold further content and services performed for or on behalf of Customer until payment in full is made plus accrued late charges of 2% per month. 10 Indemnification. Customer warrants that everything it gives Agency to use in fulfillment of services is legally owned or licensed to Customer. Customer agrees to indemnify and hold Agency harmless from any and all claims brought by any third party relating to any aspect of the services creative content or other content including but without limitation any and all demands liabilities losses costs and claims including attorneys fees arising out of injury caused by Customers products services material supplied by Customer copyright infringement and defective products sold via the advertising or services. Further Customer agrees to indemnify Agency from responsibility for problems disruptions caused by third party services and contractors that Customer may use such as media buyers transportation merchant accounts shopping carts shipping hosting services real time credit card processing and other services that relate to the execution of the services by Agency as outlined in this Agreement. 10 Use of Services and Creative Content for Promotional Purposes. Customer grants Agency the right to use the creative content description of services performed results of services and campaign data as it sees fit for promotional purposes.

10 No Responsibility for Theft. Agency has no responsibility for any third party taking all or any part of the content ideas or services provided to Customer by Agency. 10. 10 Attorneys Fees. In the event any party to this Agreement employs an attorney to enforce any of the terms of the Agreement the prevailing party shall be entitled to recover its actual attorneys fees and costs including expert witness fees. 10. 11 Term of Agreement. This agreement shall begin on current date and shall continue in full force until terminated by either party upon at least thirty days prior written notice. Both parties represent and warrant that on the date first written above they are authorized to enter into this Agreement in entirety and duly bind their respective principals by their signatures below. EXECUTED as of the date first written above. company name

By signator authorized signature or signer. Job title of signator authorized signature or signer. Date when the contact was signed company name By signator authorized signature or signer. Job title of signator authorized signature or signer. Date when the contact was signed

Customer Initials Agency Initials

A Document from Contract Pack

The editable Social Networking Services Contract template - complete with the actual formatting and layout is available in the retail Contract Packs.
Proposal Kit on BBB
Proposal Kit
Proposal Kit on FaceBook
Create winning business proposals & contracts with minimal effort and cost. Downloadable proposal software, proposal templates, legal contracts and sample proposals.
© 1997 - 2018, Proposal Kit, Inc. All rights reserved.
Proposal Kit

Create winning business proposals & contracts with minimal effort and cost. Proposal software, proposal templates, legal contracts and sample proposals.